Loading...
HomeMy WebLinkAboutBy-law 4358/93 THE CORPORATION OF TIlE TOWN OF PICKERING BY-LAW 4358/93 Being a by-law to authorize the execution of a Development Agreement between Danlu Holdings Limited Perdanco Holdings Ltd, and lnperdel Holdings Limited and The Corporation of the Town of Pickering respecting the development of parts of Plan 40M-1507, Pickering for a quattroplex residential dwellings [LD48-53/93]. WHEREAS Danlu Holdings Limited, Perdanco Holdings Ltd., and lnperdel Holdings Limited are the owners of parts of Blocks 46 and 47, Plan 40M-1507, in the Town of Picketing, in the Regional Municipality of Durham and wish to develop that land in conjunction with various adjacent parcels in accordance with Durham Land Division Committee Decisions LD48/93, LD49/93, LD50/93, LD51/93, LD52/93 and LD53/93, and are required as a condition of approval thereof to enter into a Development Agreement with the Town pursuant to section 51 of the Planning Act, R.S.O. 1990, chapter P.13; NOW THEREFORE, the Council of The Corporation of the Town of Pickering HEREBY ENACTS AS FOLLOWS: I. The Mayor and Clerk are hereby authorized to execute a Development Agreement, in the form attached hereto as Schedule A, between Danlu Holdings Limited, Perdanco Holdings Ltd., and Inperdel Holdings Limited and The Corporation of the Town of Picketing, for the purpose of permitting the development of Blocks 46 and 47, Plan 40M-1507, Picketing, and certain adjacent lands, for quattroplex residential dwellings. 2. (1) The Corporation of the Town of Pickering shall acquire those lands referred to in subsection I (1) of Schedule A to the Development Agreement for the purposes set out therein, subject to the terms and conditions set out in section 34 of the Development Agreement. (2) The Corporation of the Town of Pickering shall dispose of those lands referred to in subsections 1(2) and 1 (3) of Schedule A to the Development Agreement for the purposes set out therein. (3) The Mayor and Clerk are hereby authorized to execute any transfer/deed other document, approved by the Town Solicitor, effecting the acquisition or disposition by The Corporation of the Town of Picketing of any of the interests referred to in subsections (1) or (2) of this section. BY-LAW read a first, second and third time and finally passed this 2 2 day of .~,'ovenbart 993. THIS DEVELOPMENT AGREEMENT made August 5, 1993, pursuant to the provisions of section of the Planning Act, R.S.O. 1990, chapter P.13, BETWEEN: DANLU HOLDINGS LIMITED, PERDANCO HOLDINGS LTD., and 13FPERDEL HOLDINGS LI.M1TED herein collectively called the "Owner" OF THE FIRST PART, THE CORPORATION OF THE TOWN OF PICKERING herein called the "Town" OF THE SECOND PART. WHEREAS the Owner proposes to subdivide parts of Blocks 46 and 47, Plan 40M-1507, in the Town of Picketing, in the Regional Municipality of Durham (and to develop that land in conjunction with various adjacem parcels), in accordance with Durham I and Division Committee Decisions LD48/93, LD49/93, LD50/93, LD51/93, LD52/93 and LD53/93, and is required as a condition of approval thereof to enter into a development agreement with the Town pursuant to section 51 of the Planning Act, R.S.O. 1990, chapter P.13; NOW THEREFORE, THIS AGREEMENT W1TNESSETH THAT, in consideration of the Town issuing its advice to the Durham Land Division Committee that Condition 2 of each of that Committee's Decisions LD48/93, LD49/93, LD50/93, LD51/93, LD52/93 and LD53/93 has been carried out to the Town's satisfaction, and the covenants hereinafter expressed, the Parties hereto covenant and agree one with the other as follows: PART 1 - H¥~ t~P, PR~'~ ~IG ~ APPLYllgG THIS AGREEMF. gff The lands affected by this Agreement (herein called the "Lands") are, (a) those parts of Block 46, Plan 40M-1507, Pickering, designated as Parts 1, 2, 3 and 4, Plan 40R- 14939; (b) those parts of Block 47, Plan 40M-1507, Picketing, designated as Parts 21, 21 and 22, Plan 40R- 14939; (c) those parts of Block 48, Plan 40M-1507, Picketing, designated as Parts 23, 32 and 33, Plan 40R- 14939; (d) that part of Block 49, Plan 40M-1507, Picketing, designated as Part 31, Plan 40R-14939; (e) Blocks 53 and 54, Plan 40M-1507, Pickering; (f) that part of Block 55, Plan 40M-1507, Picketing, designated as Part 30, Plan 40R-14939; and (g) that parts of Valleyview Drive, Plan 40M-1507, Picketing, designated as Part 39, Plan 40R-14939. 2. STATUS OF THIS AGREEMENT (1) In the event this Agreement is not registered on or before April 5, 1994, this Agreement shall be null and void and of no further effect, and the Town shall not be liable for any expenses, costs or damages suffered by the Owner as a result thereof, (2) This Agreement is entered into and executed by the Owner for the purpose of having the Town act in reliance on the covenants by the Owner contained herein and the Owner hereby waives any right or claim which it now has Or may hereinafter acquire which is inconsistem with the terms of this Agreement. (I) Whenever in this A. gr,,e?me,,nt ,~he ~,ronoun "it" is used, it shall be read and construed as "he", "she", "they , 'him , her or "them", and the number of the verb agreeing therewith shall be construed accordingly. (2) Schedules A, B, C and D attached hereto shall form part of this Agreement. (3) Time shall be of the essence of this Agreement. This Agreement shall be enforceable by and against the Parties hereto, their heirs, executors, administrators, successors and assigns, and the Agreement and all the covenants by the Owner contained herein shall nm with the Lands for the benefit of the Town and the land or interests in land owned by the Town upon the registration of this Agreement. 5. NOTICE (1) Any notice required to be given hereunder may be given by personal delivery or registered mail, (a) in the case of the Owner, to Rick D'Andrea Altona West Developments P.O. Box 55, R.R. 1 Oormley, Ontario L0H IG0 and (b) in the case of the Town, to The Town Clerk The Corporation of the Town of Picketing Pickering Civic Complex One The Esplanade Picketing, Ontario LIV 6K7 (2) Each Party may redesignate the person or the address, or both, to whom or to which such notice may be given by giving written notice to the other. (3) Any notice given in accordance with this section shall be deemed to have been given on the second day following the day of delivery or the day of mailing, as the case may be. The Owner shall retain a licence from any subsequent purchaser of the Lands, or any part thereof, to enable the Owner and the Town's inspectors to enter upon the Lands in order to comply with the provisions of this Agreement. 7. OWNER'S GENERAL UNDERTAKING The Owner shall complete in a good workmanlike manner for the Town, all the municipal services as hereinafter set forth to the satisfaction of the Town, and shall complete, perform or make payment for such other matters as may be provided for herein. -2- Every provision of this Agreement by which the Owner is obligated in any way shall be deemed to include the words "at the expense of the Owner and at no expense to the Town" unless the context requires otherwise. PART 2 - CON,¥~R(ICTING THE TOWN'S SERVICES 9. CONSULTING ENGEqEERS (1) The Owner shffll retain a Professional Engineer as *,he Consulting Engineer of the Owner to carry out all the necessary engineering and to supervise the work required to be done for the development and construclion of the project. (2) Such Consulting Engineer, or any successor thereto, shall continue to be retained until the work required to be done for the development and construction of the project is completed and formally accepted by the Town. (3) The Owner may change from one Consulting Engineer to another at any time or times during the development and construction of the project, so long as the Owner has a Consulting Engineer retained at all times. 10. CONSTRUCTION / IIqSTALLATION OF TOWN WORKS AND SERVICES (1) The Owner shall obtain all required approvals and shall constmcx or install to Town standards and shall, provide to the Town, complete in every detail, the following Town works and services (the "Works") as shown on plans submitted by the Owner's Consulting Engineer to the 'Town and approved by the Town's Director of Public Works in accordance with the Town's specifications for such Works: (a) Town roads adjacent to the Lands, complete with all signs and other appurtenances; (b) street storm sewers on Town roads adjacent to the Lands, complete with curbs, gutters, catchbasins and manholes; (c) storm water drainage and management system serving the Lands and lands outside the Lands but draining through the Lands, complete with detention or retention facilities, quailW control devices and outlets; (d) boulevards and sidewalks on Town roads adjacent to the Lands; (e) street lighting on Town roads adjacent to the Lands; (f) street tree planting on Town roads adjacent to the Lands; and (g) fencing adjacent to parks, open space and storm water management facilities. (2) If at any time prior to the acceptance of the Works, the Town's Director of Public Works is of the opinion that additional works are necessary to provide adequately any of the public services required by the project, the Owner shall construct, install or perform such additional works at the request of the Director. (3) All Works shall be constructed and installed in accordance with the Town's specifications and in a good and workmanlike manner under the supervision of the Owner's Consulting Engineer and under the observation of the Town's inspectors or, in the case of street lighting, Picketing Hydro's inspectors. (4) The Owner shall conduct video inspections of all underground services required to be constructed or installed hereby and shall provide a VHS-format videotape record of those inspections to the Town. (5) The owner shall pay to the Town the Town's costs of inspection, including but not necessarily limited to, salaries and wages of inspectors, testing fees and administration fees, within 30 days of invoices being rendered. -3- 11. GENERAL REGULATIONS RESPECTING SERVICING (1) The construction of Town roads shall include the construction of paved driveway approaches between the curb and sidewalk or, where no sidewalk is to be provided, between the curb and the lot line. (2) Where the construction or installation of services involves a continuation or extension of existing services, the Owner shall join into the existing services, including adjustment of grades where necessary, in a good and workmanlike manner. (3) The Owner shall not dump nor permit to be dumped any fill or debris on, nor remove or permit to be removed any fill from, any public lands, other than in the actual construction of roads in the project without the written consent of the authority responsible for such lands. (4) The Owner shall not bum nor permit to be burned any refuse or debris within the project or adjacem to it. (5) The Town's Director of Public Works may have qualitative or q}lantitative tests made of any materials which have been or are proposed to be used m the construction or installation of any services required by this Agreement, and the cost of such tests shall be paid by the Owner within 30 days of invoices being rendered. (6) The Owner shall pay, within 30 days of invoices being rendered, the costs of, (a) relocating any existing services or utilities required to be relocated by the construction or installation of Works, services, or utilities in the project, and (b) moving any Works, services or utilities installed in driveways or so close thereto, in the opinion of the Town's Director of Pubhc Works, as to interfere with the use of the driveway. (7) Unless otherwise provided herein, the Owner shall perform any woflt required to he done under this Agreement to the specifications of the Town in effect at the date hereof. (8) The Owner shall provide and erect temporary signs of such nature and at such locations as designated by the Town's Director of Public Works. 12. ELECTRICAL SERVICES Where electricity, cable television service or telephone service is to be provided to any lot or block in the project, it shall be provided underground and in accordance with the standards and specifications of Picketing Hydro-Electric Commission, Trillium Cable T.V. Limited or Bell Canada, as the case may be. 13. TREE INVENTORY / TREE PRESERVATION PROGRAM (1) The Owner shall submit a Tree Inventory and a Tree Preservation Program prepared by a qualified expert, and based upon the Town-approved Grading Control Plan, indicating which existing trees in the project may be preserved to the Town's Director of Public Woflcs for the review and approval of the Town's Director of Planning and Director of Community Serv ices and Facilities, and shall implement the Program as approved only. (2) Until the Tree Preservation Program is approved the Owner shall not commence, nor allow to be commenced, any aspect of the development of the lands in the project, including the removal of any tree. (3) In the event that any tree required to be preserved by the approved Tree Preservation Program is removed or is, in the opinion of the Town's Director of Community Services and Facilities, damaged to such an extent that its value or longevity is decreased or is likely to be decreased, then the Owner shall replace that tree with a tree of a height, diameter and species determined by the Director; such replacement shall be at no cost to the Town. (4) The Owner's liability under subsection (3) shall continue until, (a) where the lands upon which the tree is located comprise a residential building lot or block, twelve months after the completion of the sodding on the lot or block, or -4- (b) where the lands upon which the tree is located comprise lands other than a residential building lot, the issuance by the Town of the Final Acceptance Certificate. 14. GRADING CONTROL PLAN / LOT DRAINAGE AND SODDING (I) The Owner shall submit to the Town, for the approval of the Town's Director of Public Works, a Grading Control Plan (including a stormwater capacity assessment) prepared by the Owner's Consulting Engineer, establishing the proposed grading of the Lands to provide for the proper drainage thereof and the drainage of ail adjacent lands which drain through the Lands. (2) The Grading Control Plan shall be prepared in accordance with the Town's Lot Drainage Specifications and shall not provide for the drainage of surface mn-off water omo Town-owned parkland, open space or walkways unless provision is made for the installation by the Owner, at no cost to the Town, of suitable swales and catch basins to manage adequately, in the opinion of the Town's Director of Community Services and Facilities, that surface mn-off water. (3) The Owner shall gxade the Lands in accordance with the approved Grading Control Plan, ensuring that sufficient topsoil remains as cover on all areas of the project intended for sodding, seeding, or other planting. (4) If the Town determines that, (a) grading has not been done in accordance with the Grading Control Plan, (b) grading has been done in accordance with the Grading Control Plan but drainage problems remain, or (c) sufficient topsoil has not been left in the appropriate a~eas, the Owner shall re-grade the Lands, or part thereof affected, adding a sufficient amount of topsoil ff necessary, or construct catch basins, swales or other structures as may be necessary to correct such problems, as directed by the Town's Director of Public Works. (5) The Owner shall sod the front, side and rear yards of each of the residential lots and blocks in the project except for paved, planted or treed areas prior to the occupancy of the dwelling unit located thereon or within the six months immediately thereafter except, where the occupancy of the dwelling unit occurs in November or December of any year, the time limit for sodding may be extended to Sune 30 in the following year. 15. ALrI~ORIZATION TO COMMENCE WORK The Owner shall not commence the construction or installation of any of the Works without the written Authorization to Commence Work of the Town's Director of Public Works, which Authorization shall not be issued until all approvals required by this Agreement have been obtained and, (a) four red-lined copies of this Agreement executed by the Owner and all Encumbrancers have been provided to the Town to the satisfaction of the Town Solicitor; (b) all monies, securities and insurance policies, as noted in this Agreement, have been delivered to the Town to the satisfaction of the Town Treasurer and the Town Solicitor; (c) all approvals and permits have been obtained by the Owner from the Ministry of the Environmem, the Ministry of Natural Resources and the Metropolitan Toronto and Region Conservation Authority, or a certificate has been provided by the Owner's Consulting Engineer that no such approvals or permits are required; and (d) three executed copies, in a form suitable for registration, of any Transfers/Deeds required by section 34 respecting the conveyances identified in Schedule A have been provided to the Town in registrable form to the satisfaction of the Town Solicitor. 16. USE OF WORKS PENDING COMPLETION / EMERGENCY REPAIRS (1) Any of the Works may be used by the Town, or by such other person or agency as may be authorized by the Town's Director of Public Works, for the put'poses for which the Works are designed, and such use shall not be deemed an acceptance of any of the Works by the Town, nor an assumption by the Town of any liability in connection therewith, nor a release of the Owner from any of its obligations under this Agreement. (2) The Town may make emergency repairs at any time to any of the Works and may for this purpose enter the Lands at any time; such repair or entry shall not be deemed an acceptance of any of the Works by the Town, nor an assumption by the Town of any liability in connection therewith, nor a release of the Owner from any of its obligations under this Agreement. 17. INTERNAL / EXTERNAL ROAD MAINTENANCE AND REPAIR / SNOW PLOWING (1) Throughout the term of this Agreement, the Owner shall, (a) maintain all Town roads adjacent to the Lands in a mud and dust free condition and free of obstructions, regardless of the source or cause of any mud, dust or obstruction; (b) maintain all Town roads outside the project, including boulevards, in a mud and dust free condition and free of obstructions, where the source or cause of the mud, dust or obstruction is an operation or operations related in any way to the development of the project; (c) repair all Town roads outside the project, including boulevards, where damage has occurred as a result of an operation or operations related in any way to the development of the project; and (d) plow snow from and salt all Town roads adjacent to the Lands that are not subject to the Town's winter control program. (2) The Owner, within 24 hours of verbal notification by the Town to it or its representatives, shall undertake such works as are necessary to clean, clear, repair, plow or salt any Town road requiring such work in the opinion of the Town's Director of Public Works or his designate. 18. COMPLETION DATES - TOWN WORKS AND SERVICES (1) The Owner shall complete the Works in accordance with the following time limits: (a) Town roads - two years from date of Authorization to Commence Work; (b) street storm sewers - one year from date of Authorization to Commence Work; (c) storm water drainage and management system (including grading and top-soiling of non-residential lots and blocks) - one year from date of Authorization to Commence Work; (d) boulevards and sidewalks - six months after occupancy of first dwelling to be occupied adjacent to segment as identified by the Town's Director of Public Works, but no later than two years from date of Authorization to Commence Work; (e) street lighting - one year from date of Authorization to Commence Work; (f) street tree planting - two years from date of Authorization to Commence Work; (g) fencing - prior to the occupancy of any dwelling adjacent thereto, following the satisfactory completion and testing of ali of which, and the approval thereof by the Town, the Town shall issue to the Owner a Completion Acceptance Certificate. (2) Despite the provisions of subsections (l)(d) and (1)(g), where the occupancy of the fixst dwelling unit occurs in November or December of any year, the time limit for construction of the adjacent boulevard, sidewalk or fencing segment shall be extended to June 30 in the following year. 19. FAILURE TO COMPLETE / IMPROPER PERFORMANCE (1) If, in the opinion of the Town's Director of Public Works, the Owner is not constructing or installing the Works, or causing them to be constructed or installed, within the specified time or so that they may be completed within the specified time, or is improperly performing the Works, or has neglected or abandoned them before completion, -6- or has unreasonably delayed them so that the terms and conditions of this Agreement are being violated or executed carelessly or in bad faith, or has neglected or refused to renew or again perform Works rejected by the Director of Public Works as defective or unsuitable, or has in any other manner, in the opinion of the Director of Public Works, defaulted in the performance of the terms and conditions of this Agreement, then the Di~ctor may notify the Owner and his surety in writing of the default or neglect and if the notification be without effect for seven days, then the Director shall have full authority to make any payment or do any thing, including but not limited to obtaining materials, tools and machinery and employing 'persons required for the proper completion of the Works or rectification of the default, at the cost and expense of the Owner or his surety, or both. (2) In cases of emergency, in the opinion of the Director of Public Works, such Director may act without prior notice but the Owner and its surety shall be notified forthwith. (3) The cost of rectifying the default shall be calculated by the Director of Public Works, whose decision shall be final, and may be charged to the Owner, together with a 25 per c~nt engineering and administration fee, by drawing upon the letter of credit f'Red with the Town under section 21. 20. GUARANTEE OF WORKS. WORKMANSHIp AND MATERIALS (I) The Owner shall guarantee all Works, workmanship and materials employed or used in ' the. construction, installation or completion of Works, services and other requirements under this Agreement for a minimum period of two years (the "maintenance period") following the issuance of the Completion Acceptance Certificate by the Town. (2) Despite any other provisions of this Agreement, the responsibilities of the Owner during the maintenance period shall include the maintenance of the Works, including the rectification of any unsatisfactorily installed Works. (3) Prior to the end of the maintenance period, the Owner's Consulting Engineer shall submit to the Town, (a) "as built" constmcrion drawings for the Works complete as per Town standards, together with that Consulting Engineer's certificate that those drawings accurately depict the Works as constructed; and (b) a statement by an Ontario Land Surveyor that all standard iron bars shown on Plan 40M-1507 and on Plan 40R-14939 have been found or re-established. (4) Prior to the end of the maintenance period, the Town will re-inspect the Works and if, (a) the Works are acceptable; and (b) the Owner has .performed all of its obligations under the terms of this Agreemem to the satisfaction of the Town, the Town will issue to the Owner a Final Acceptance Certificate at which time the Town will assume ownership of the Works and the operation and maintenance thereof, and the maintenance period will then end. (5) If upon the re-inspection conducted prior to the end of the maintenance period, (a) the Works are not acceptable, or (b) the Owner has not performed all of its obligations under the terms of this Agreement to the satisfaction of the Town, the Town will advise the Owner of the deficiencies, the expected rectifications, and the time limited for implementing the rectifications (the "rectification period") and the maintenance period shall be extended to the end of the rectification period. (6) At the end of the rectification period, the Town will re-inspect the Works and if, (a) the Works are acceptable; and (b) the Owner has performed all of its obligations under the terms of this Agreement to the satisfaction of the Town, -7- the Town will issue to the Owner a Final Acceptance Certificate at which time the Town will assume ownership of the Works and the operation and maintenance thereof, and the maintenance period will then end. (7) If upon the re-inspection conducted at the end of the rectification period, (a) the Works are still not acceptable, or (b) the Owner has not performed all of its obligations under the terms of this Agreement to the satisfaction of the Town, the Town's Director of Public Works shall determine, in his sole discretion, whether a further rectification period will be granted, and, ff so, upon what terms and conditions, or whether the Town shall proceed under the provisions of section 19, or both. 21. PERFORMANCE AND MAINTENANCE SECUR/TY (1) Before this Agreement will be executed by the Town, the Owner shall file with the Town an irrevocable letter of credit, issued by a chartered bank in Canada in the form set out in Schedule B and in an amount established by the Director of Public Worka (the "original value"), as a performance and maintenance security for the purpose of, (a) guaranteeing the satisfactoO, construction, installation or performance of the Works; (b) guaranteeing the payment of any amounts payable to the Town under this Agreement; (c) guaranteeing the payment of any amount that the Town may be required to pay under the provisio.ns of the Cortstruction Lien Act, or any successor thereto, and (d) guaranteeing all Works, workmanship and materials during the maintenance period and any rectification period or periods and until a Final Acceptance Certificate has been issued by the Town's Director of Public Works. (2) The Owner may, at any time after the first 50 per cent, in value, of Works have been constructed, installed or performed, and paid for, apply for a reduction in the security and such application shall be made to the Town Treasurer. (3) Upon written verification from the Director of Public Works that the construction, installation or performance of the Works for which reduction is being sought have been satisfactorily completed and paid for, the Town Manager may reduce the amount of the security to an amount not less than, (a) 60 per cent of the original value where no certificate or declaration of substantial performance has been made; (b) 35 per cent of the original value where, (i) a certificate or declaration of substantial performance has been published; (ii) 45 days following such publication have expired; and (iii) all liens that may be claimed against any holdback requh'ed to be retained by the Town have expired or have been satisfied, discharged or provided for by payment into court; and (c) 17 per cent of the original value where, (i) a certificate of final completion has been made by the Owner's Consulting Engineer; (ii) 45 days following the making of such certificate have expired; (iii) all liens that may be claimed against any holdback required to be retained by the Town have expired or have been satisfied, discharged or provided for by payment into court; and (iv) a Completion Acceptance Certificate has been issued by the Town's Director of Public Works, -8- which 17 per cent portion shall secure the guarantee of Works, workananship and materials, until a Final Acceptance Certificate has been issued by the Town's Director of Public Works, when the balance of the security shall he returned to the Owner subject to any deductions for rectification of deficiencies. (4) Upon the approval, if any, of a reduction in the amount of the security required to be provided in subsection (1), the Town Manager or the Town Treasurer shall provide to the Owner any necessary assurance to effect the reduction. 22. QWNER'S GENERAL INDEMNITY Until the Town's Director of Public Works has issued the Final Acceptance Certificate for the Wodrs, the Owner shall indemnify the Town against all actions, causes of actions, suits, claims and demands whatsoever, which may arise either directly or indirectly by reason of the Owner undertaking the project or servicing the Lands as required under this Agreement. 23. OCCUPATIONAL HEALTH AND SAFETY (1) The Owner certifies that it is aware of its duties and obligations under the Occupational Health and Safety Act, or any successor thereto, and all Regulations thereunder (herein called the "Act"), and shall ensure that its employees, contractors, subcontractors and their employees, (a) are aware of their respective duties and obligations under the Act, and (b) have sufficient knowledge and training to perform all works and services required pursuant to this Agreement safely and in compliance with the Act. (2) In the performance of all works and services required pursuant to this Agreement, the Owner shall, (a) act safely and comply in all respects with the Act, and (b) ensure that its employees, contractors, subcontractors and their employees act safely and comply in all respects with the Act. (3) The Owner shall rectify any unsafe act or practice and any non-compliance with the Act immediately upon being notified by any person of the existence of such act, practice or non-compliance. (4) The Owner shall permit representatives of the Town on the site where any works or services required pursuant to this Agreement are being performed at any time or times for the purpose of inspection to determine compliance with this section. (5) No act or omission by the Town or any representative of the Town (including the entering into of this Agreement) shall he deemed to be an assumption of any of the duties or obligations of the Owner, its employees, contractors, subcontractors and their employees under the Act. (6) In addition to the Owner's general indemnification of the Town pursuant to section 22, above, the Owner shall indemnify and save hamdess the Town, (a) from any loss, inconvenience, damage or cost to the Town which may result from the Owner or any of its employees, contractors, subcontractors and their employees failing to act s',ffely or to comply in all respects with the Act in the performance of any work or service required pursuant to this Agreement; and (b) against any action or claim, or costs related thereto, brought against the Town by any person arising out of any unsafe act or practice or any non--compliance with the Act by the Owner or any of its employees, contractors, subcontractors and their employees in the performance of any work or service required pursuant to this Agreement. 24. LIABILITY INSURANCE POLICY / PROVISION FOR DEDUCTIBLE (1) Before this Agreement will be executed by the Town, the Owner shall file with the Town a Certificate of Insurance verifying that a Liability Insurance Policy is in effect, setting out the essential terms and conditions of the insurance, and naming the Town as additional named insured, all of which shall be subject to the approval of the Town Solicitor. -9- (2) The policy shall comply with the following provisions: (a) the minimum limit per occurrence shall be $5,000,000 all inclusive for property damage and personal liability; (b) it shall not contain a clause for exclusion for blasting; and (c) it may not be cancelled unless prior notice by registered letter has been given to the Town by the insurer thirty days in advance of the expiry date. (3) The policy premium must be paid init/ally for a period of one year and the policy shall be renewed for further one year periods until the Final Acceptance Certificate has been issued by the Town's Director of Public Works. (4) If the policy coverage is subject to a deductible amount, the Owner shall ftc with the Town, when filing the Certificate of Insurance, a certified cheque or letter of credit with the Town in the deductible amount, as a deposit, together with a letter from the Owner authorizing the Town to appoint an indelpendent adjuster and to investigate claima less than the deductible amount and authorizing the Town to pay such claima deemed valid by the adjuster out of the deposit; the Owner shall be responsible for all adjustment service costs and shall maintain the deposit throughout the term of this agreement in the amount of the deductible. (5) The provision of the insurance policy required by this section shall not relieve the Owner from liability for claims not cover~d by the policy or which exceed its limits, ff any, for which the Owner may be held responsible. PART $ - DEVI~.OPING THE PROJECT 25. CONSTI~UCTION AND OCCUPANCY OF BUILDINGS (1) No 'building permit shall be issued for any building or part of a building on the Lands until, (a) sewer and water facilities are available, and in the opinion of the Town's Director of Public Works, capable of providing adequate service; (b) an asphalt base has been laid on the road immediately in front of the building or part thereof and extended to an existing maintained road; and (c) the Owner has paid to the Town the applicable development charge for each dwelling in that building or part thereof in accordance with By-law 3854/91, enacted pursuant to the Development Charges Act. (2) No building or part of a building on the Lands shall be occupied except upon the issuance of a municipal occupancy permit. (3) No application for a municipal occupancy permit for a building or pan of a building shall be made except upon the following conditions: (a) storm sewer, sanitary sewer and water facilities are installed and in operation to adequately serve such building or pan thereof; (b) electric service is completed and in operation; and (c) such curbs, as in the opinion of the Town's Director of Public Works, are required to be completed prior to occupancy have been constructed on the road immediately in front of the building or part thereof and extended to an existing maintained public road. (4) The Owner shall maintain vehicular access to all occupied buildings on the Lands. 26. DESIGN PLANNING - RESIDENTIAL UNITS AND NOISE ATFENUATION STRUCTURES (1) Prior to the issuance of any building permit for the construction of any residential unit on the Lands and the construction of any noise attenuation structure in or adjacent to the project, the Owner shall submit to the Town's Director of Planning, for approval, a report outlining siting and architectural design objectives for the project. -10- (2) That report may be required, at the Director's option, to provide the following information: (a) house massing; (b) streetscapo; (c) exterior materials and colours; (d) architectural style; (e) visual variety; energy conse~wation measures; and (g) any other data or information reasonably required. (3) Prior to the issuance of each building permit for the construction of a residential unit on the Lands, the Owner shall submit to the Town's Director of Planning, for approval, site plans and architectural drawings for that unit. (4) Those plans and drawings may be required, at the Director's option, to provide the following information: (a) the location of all buildings and structures to be erected and the location of facilities and works associated therewith; (b) the location of landscaping features, including t~es to be preserved; (c) stree~scape for front, rear and flank, age elevations at a scale acceptable to the Director; (d) suceetscape to show all street furniture and vegetation; (e) the relationship of buildings by blocEs; and (0 any other data or information reasonably requi~d. 27. SPECIFIC PROVISIONS RESPECTING DEVELOPMENT The Owner shall comply with any specific provisions respecling the development of this project set out in Schedule D. PART 4 - FI~IANCIAL ~ 28. EXPIRY OF SECURIFIES (1) Should any letter of credit security required to be provided hereunder expire before the Town releases the Owner from the terms and conditions hereof, the Owner shall provide to the Town at least 30 days in advance of the expiry date of that security, a further security to take effect upon the expiry. (2) Such further security shall be in a form and amount satisfactory to the Town. (3) Should no such further security be provided as required, then the Town shall have the right to convert the expiring security into cash and hold the cash in lieu of and for the same purposes as the expiring security. 29. PAYMENT OF LIENS AND OTHER CLAIMS (1) The Owner shall discharge or vacate any liens or claims fi/ed with the Town or registered on title to any Town-owned lands within thirty days of being requested to do so by the Town. (2) At the end of the maintenance period, as extended during any rectification period, the Owner shall fde with the Town a Statutory Declaration stating that, (a) all materials have been supplied and all services and works have been completed in the project with respect to the construction and installation of Works and other services; (b) all accounts for work or service performed and materials placed or furnished upon or in respect of the construction and installation 'of Works and other services in the project have been fully paid and satisfied and no person is entitled to claim a lien under the Construction Lien Act against the Town or any Town-owned land; (c) there are no judgments or executions filed against the Owner; -11- (d) nothing is owed by the Owner or claimed against it for unemployment insurance deductions, income tax deductions, or by way of contribution or assessment under the Workers' Comper~ation Act; (e) the Owner has not made any assignment for the benefit of creditors, nor has any receiving order been made against it under the Bankruptcy Act, nor has any petit/on for such an order been served upon the Owner; and (f) 45 days have passed since the completion of the construction, installation, and last rectification of the Works and services. 30. PAYMENT OF INTEREST ON OVERDUE AMOUNTS PAYABLE The Owner shall pay interest at the rate of 18 per cent per year to the Town on aH stuns of money payable hereunder which are not paid on the due dates calculated from such due dates. 31. p/~.YMENT OF REALTY AND BUSINESS TAXES / LOCAL iMPROVEMENT CHARGES (1) The Owner shall pay in full as they come due all realty and business taxes assessed against the Lands or the Owner as requi~ed by law from time to time. (2) 'Befgre this Agreement will be executed by the Town, the Owner shah commute and pay to the Town or to the Regional Municipality of Durham aH local improvement charges assessed against the Lands. 32. PAYMENT OF DEVELOPMENT CHARGES (1) The Owner shah pay to the Town, in accordance with the Development Charges Act and the Town's Development Charges By-law 3854/91, development charges for each dwelling unit within the project respecting the following services: (a) administrative services - town offices; (b) administrative services - capital growth studies; (c) protection - fzre facilities; (d) protection - f~e vehicles and equipment; (e) storm drainage, roads, sidewalks, storm sewers, lighting and other services; (f) transportation - works yards, vehicles and equipment; (g) transportation - transit; (h) parks - parkland acquisition; (i) parks - parkland development; O) major recreational facilities - major indoor recreational facilities; (k) library - library facilities; (1) library - library materials; and (m) electrical distribution services and facilities. (2) The amount of the development charge for each dwelling to be erected on the Lands shah be the amount set out in Schedule C for that type of dwelling, as adjusted annually in accordance with Schedule C. 33. PAYMENT OF ENGINEERING. LEGAL AND REGISTRATION FEES (1) Before this Agreement will be executed by the Town, the Owner shaH pay by certified cheque to the Town an Engineering Drawing Inspection Fee in the amount set out in Schedule C for the examination and inspection done by the Town's Public Works Department in the processing of the engineering drawings for this project. (2) Before this Agreement will be executed by the Town, the Owner shaH pay by certified cheque to the Town a Development Agreement Processing Fee in the amount set out in Schedule C for the preparation and processing of this Agreement by the Town's Legal Services Department. (3) The Owner shallpay all registration costs incurred by the Town relating in any way to the registration of this Agreement and any other documentation, including transfers, in the Land Registry Office within 30 days of invoices beh'~g rendered. -12- 34. TRANSFERS OF LANDS OR INTERESTS I~ LANDS OR PAYMENTS IN LIEU THEREOF (1) Upon executing this Agreement, the Owner shall convey or cause to be conveyed to the Town, free and clear of all encumbrances and at no cost to the Town, all of the lands or interests in lands identified in Schedule A for the purposes set out therein. (2) The Owner hereby warrants that, upon such conveyance, neither the title to the lands conveyed nor their physical state and condition shall prevent the Town from lawfully or ~mhysically using the lands for the purposes for which they are being conveyed as set out Schedule A. (4) Any Transfer/I~ed given pursuant to this Agreement shall be in a form acceptable to the Town Solicitor and any Transfer/Deed of a storm drainage works easement shall contain the Storm Drainage Work~ Easement Schedule set out in Schedule A. (5) The Town may complete or alter any description of land in this Agreement or in any Transfer/Deed given pursuant to this Agreement so ~ to make th~ description correspond with the description of the land according to the Land Titles Registrar. 35. ISSUANCE OF ADVICE TO DURHAM LAND DMSION COMMrITEE Before the Town will advise the Durham Land Division Committee that Condition 2 of each of that Committee's Decisions LD48/93, LD49/93, LD50/93, LD51/93, LD52/93 and LD$3/93 has been carried out to the Town's satisfaction, the Owner shall deliver to the Town the following: (a) four red-lined copies of this Agreement executed by the Owner and all Encumbrancers; (b) all monies, securities and insurance requffed by this Agreement; (c) three executed copies, in a form suitable for registration, of each Transfer/Deed required by section 34 respecting the conveyances identified in Schedule A, and one drafl copy of each required reference plan. 36. REGISTRATION OF AGREEMENT (1) This Agreement shall be registered by the Town in the Land Registry Office for the Land Titles Division of Durham (No. 40). (2) The Owner shall give to every purchaser of the Lands or any part of the Lands actual notice of the existence and the terms of this Agreement and shall include an acknowledgement in any offer to purchase or other similar document dealing with the Lands, or any part of them. (3) The Owner shall indemnify and save harmless the Town from any loss, inconvenience or damage which may result to the Town from the Owner's failure to comply with subsection (2) and against any action or claim made against the Town by any person other than the Owner arising out of the execution by the Town of this Agreement. (4) The Owner shall execute such further assurances of the rights hereby granted as may be deemed necessary by the Town. IN WITNESS WHEREOF, the companies comprising the Owner have hereunto affixed their respective corporate seals, attested by the hands of their authorized officers and the Town has hereunto af-f'Lxed its corporate seal, attested by the hands of its authorized officers. SIGNED, SEALED & DELIVERED DANLU HOLDENGS LIMI'IED PERDANCO HOLDINGS LTD. INPERDEL HOLDINGS LIMITED THE CORPORATION OF THE TOWN OF PICKERiNG Wayne Anhurs, Mayor Bruce Taylor, Clerk ENCUMBRA~CER-. ROYAL BANK OF CANADA The Encumbrancer hereby postpones any dghts or interests which it has in the Lande with the intent that this Agreement shall take effect as though executed and registered prior to the creation of any such fight or interest and prior to the execution and registration of any mortgage, agreement or other document creating or defining any such right or interest; And the Encumbrancer hereby covenants and agrees with the Town that this Agreen~nt and any conveyance, easement or other document given pursuant to this Agreement, shall have priority over the rights of the Encumbrancer in the Lands with the intent that the Encumbrancer or anyone claiming under it shall at no time exercise in relation to the Lands any right, title or claim which could not be exercised by the Owner by reason of the terms of this Agreement. Dated at , ~ ' day of ,1993. SIGNED, SEALED AND DELIVERED ROYAL BANK OF CANADA -14- TRANSF~ OF L.4NL~ OR ~ IN L.4ND$ OR PArlff~ l~l LIE(I IIIEREOF (Section 34) 1. (1) (~ONVEYANCES REOUIRED TO BE MADE TO THE TOWN Part 8, Plan 40R-14939 Road (Homer Court) Fee simple Parts 10 and 26, Plan 40R-14939 Parkland Fee simple . Any portion of the Lands Storm drainage works Easement determined by the Town's Director of Public Works Any lands outside the Lands Storm drainage works Easement determined by the Town's Director of Public Works (2) CONVEYANCES REQUIRED TO BE MADE TO THE OWNER Parts 5, 20, 21, 22, 23, 29, 30, Residential Fee simple 31, 32, 33 and 34, Plan 40R-14939 Blocks 53 and 54, Plan 40M-1507 Residential Fee simple (3) CONVEYANCES REQUIRED TO BE MADE TO OTHERS Land to be Conveyed to Owner of Lot 42. Plan 40M-1507 ~ ~ Block 51, Plan 40M-1507 Residential Fee simple Land to be Conveyed to Owner of Lot 43. Plan 40M-1507 Pu .rpose nv Block 52, Plan 40M-1507 Residential Fee simple Part 39, Plan 40R-14939 Residential Fee simple Land to be Conveyed to Owner of Lot 40. Plan 40M-1508 Purpo. se Interest to be Conv~yegl Block 49, Plan 40M-1508 Residential Fee simple Land to be Conveyed to Owner of Lot 41. Plan 40M-1508 Purpo. se ~ Block 48, Plan 40M-1508 Residential Fee simple 2. PARKLAND PROVISIONS (1) Pursuant to the provisions of section 33 of the Subdivision Agreement, as amended, between the Owner and the Town respecting the development of Plan 40M-1508, Pickering, the Owner has a parkland credit of credit of 1.5919 hectares. (2) For the 28 dwelling units to be erected on the Lands, that parkland credit is decreased (by 0.13881 hectares) from 1.5919 hectares to 1.45309 hectares. -15- (3) In consideration of the Town conveying to the Owner Parts S, 20, 21, 22, 23, 29, 30, 31, 32, 33, 34 and 39, Plan 40R-14939, for residemial purposes, the Owner hereby surrenders 0.8094 hectares of that parkland credit, thereby decreasing that credit from 1.45309 hectares to 0.64369 hectares, which credit will remain for the Owner's use in satisfying any future obligation upon it to convey parkland to the Town· 3. STORM DRAINAGE WORKS EASEMENT REFERENCE PLANS (1) Before the Town will advise the Durham Land Division Committee that the a~propriate conditions of severance approval affecting the Town have been satisfied, the Owner shah obtain and deliver to the Town one draft copy of each proposed reference plan required to effec~ the conveyance of the specit'lc easement refer~d to in section I of this Schedule. (2) Ul~.n the completion of the construction and installation of the storm drainage works within each easement shown on any proposed reference plan, the Owner's Consuhing Engineer shall advise the Town's Director of Public Works of the actual location of the works in relation to the proposed easement or easements, and if the Director is satisfied with the actual location of the works, the Owner shall register that reference plan and provide four copies of the plan as registered to the Town Solicitor. (3) If the Town's Director of Public Works is not satisfied with the actual location of the works in relation to the proposed easement or easements, the Owner shall obtain and deliver to the Town one 'draft copy of a revised proposed reference plan, and the provisions of subsection (2) and of this subsection wi/I continue to apply. (4) Where the Town's Director of Public Works determines that the Town requires easements not specifically referred to in section I of this Schedule, the Owner shall obtain and deliver to the Town one draft copy of each pmposed reference plan required to effect the conveyance of the such easements within 30 days of the Town's request to do so, and the provisions of subsections (2) and (3) will apply. 4. STORM DRAINAGE WORKS EASEMENT SCHEDULE Where a conveyance of an easement is for storm drainage works purposes, the following Schedule shall be attached to the Transfer/Deed of Easement: (7) I~ITEREST/ESTATE TRANSFERRED Subject to the following terms and conditions, the free, uninterrupted and unobstructed right and easement to lay, construct, operate, maintain, inspect, alter, repair, replace, reconstruct and remove storm drainage works together with appurtenances thereto (herem called the "works"), in, over, along, across, upon and under the land described in Box 5 (herein called the "lands"), and to drain storm water in, over, along, across, upon and under the lands, together with the right to the Transferee, its servants, agents and contractors with aH necessary vehicles, supplies and equipment to enter onto the lands and pass and repass over the lands for the purpose of exercising or enjoying any of the rights granted herein. The terms and conditions which the parties hereto covenant and agree to observe and be bound by are as follows: 1. The Transferee shall, except in case of emergency, before commencing any work authorized hereby, give to the Transferor forty-eight hours previous written notice thereof, and in cases of emergency such previous notice thereof as is reasonably possible. 2. Upon completion of any work, the Transferee shall fill in all excavations, restore fences, and restore the surface of the ground by restoring all topsoil and grass cover disturbed thereby, and do necessary grading to ensure soil and slope stability, and remove all equipment. 3. The Transferor shall not erect any building or structure (except a fence) on the lands, and shall not place or remove any fill on or from any part of the lands without the previous written consent of the Transferee. -16- 4. The fight and easement granted herein shall be subject to all leases, licences, and any rights of use or occupation existing at the date hereof, and the Transferor may from time to time renew or extend these or make new ones, so long as they do not intedere unreasonably with the fight and easement herein granted. 5. The Transferor hereby releases the Transferee from any claim which may mi,se out of the exercise by the Transferee of the right and easemem granted hereby or which may arise out of the existence of the storm water or the existence, operation or non-operation of the storm d~ainage works provided the Transferee has complied with all of the terms and conditions herein. 6. The Transferor shall execute such further assurances of the fight and easement granted hereby as the Transferee may reasonably request in writing. 7. The burden of this Transfer and of all the terms and conditions contained herein shall mn with the lands. 8. This Transfer and all of the terms and conditions contained here'm shall enure to the benefit of and be binding upon the Transferor and the Transferee and their respective heirs, executors, administrators, successors and assigns. LAND BENEFITTED (DOMINANT 't'~EMENT) 9. The benefit of this Transfer and all of the terms and conditions contained herein shall nm with all other lands and interests in lands owned, occupied or used by the Transferee for the pu~oose of operating and maintaining storm drainage workz. - l?- RFA2UIRED FORtd FOR PERFORMANCE AND MAINII~IVANCE SECURIT'g' LETTER OF CREDIT (Section 21) To: The Corporation of the Town of Picketing Picketing Civic Centre One The Esplanade Picketing, Ontario LIV 6K7 We hereby authorize you to draw on [.ame of bank], [addre~ of bank], for account of [name of company or companies vt,raining security] up to an aggregate amount of am//~f~d/] available by drafts at sight for 100% of demand az follows: Pursuant to the request of our customers(s), the said [~at~e of co.vary or secm.ity], we [name of bank], [addre ofban ], hereby establish and give to you an in'evocable Letter of Credit in your favour in the total amount of [amo~mt ofsec~'//y/~ tmmbers a~d/~ ~oed~] which may be drawn on by you at any tLrne and from time to time upon written demand for payment made upon us by you which demand we shah honour without enquiring whether you have a right ~z between yourself and our said customer(s or any of them) to make such demand, and without recognizing any claim of our said customer(s or any of them). Provided, however, that you are to deliver to [name of bank], [address of ba~], at such time az a written demand for payment is made upon us a certificate signed by you agreeing or con/u'ming that monies drawn pursuant to this Letter of Credit are payable to you or are to he or have been expended pursuant to obligations incurred or to he incurred by you with reference to your /'de reSarding a .Development Agreement dated [date of Agreemerd], between [name of ~ig~atories to Asreement, than Town and ~ancer(#)] and The Corporation of the Town of Picketing; this Letter of Credit is giyen as the Performance and Maintenance Security required by section 21 of that Agreement. Partial drawings are permitted. The amount of this Letter of Credit shah be reduced from time to time as advised by notice in writing given to us from time to time by you. This Letter of Credit will continue up to and including [date of expiry of Letter of Credit] and will expire on that date and you may call for payment of the full amount outstanding under this Letter of Credit at any time up to the close of business on that date· It is a condition of this Letter of Credit that it shall be deemed to be automatically extended for one year from the present or any future expiration date hereof, unless thirty days prior to any such date, we shall notify you in writing by registered mail that we elect not to consider this Letter of Credit renewed for any such additional period. We hereby covenant with drawers, endorsers, and bona fide holders of drafts drawn under and in accordance with the terms of this credit that such drafts will be duly honoured if drawn and negotiated on or before [date of expiry of Letter of Credit]. The drafts drawn under this credit are to be endorsed hereon and shah state on their face that they are drawn under [name ofbanlc], [address of bank]. DATED this day of ,19 Instructions for completing Letter of Credit: 1. Letter of Credit must be typed on bank letterhead. 2. Information required in square brackets must be provided where indicated, without brackets. 3. Phrases shown in round brackets must be included without brackets where there are two or more companies comprising the customer. 4. The date in the sixth paragraph must be at least one year from the date of the Letter of Credit. 5. The date in the seventh paragraph must be the same as the date in the sixth paragraph. 6. Bank signatories must show ttame, printed or typed, and title, in addition to signature. -18- DEVELOPM~IT CHARGE, S, EIVG~IEF. RING AND LF_.GAL F~--b'~ (Sections 32 and 33) 1. DEVELOPMENT CHARGES PAYABLE (I) Until and including October 7, 1993, the development charge payable under the Town's Development Charges By-law 3854~1 for each dwelling unit within this project is $4,337. (2) From and after October 8, 1993, the development charge payable for each dwelling unit within this project will be as set out in subsection (1) as adjusted on October 8, 1993, and annually on every October 8 thereafter until paid, in accordance with the Engineering News Record Cost Index (Toronto). (3) The development charge set out in subsection (1) has been derived as follows: administrative services - town offices $325 administrative services - capital growth studies 74 protection - fire facilities 80 protection - fire vehicles and equipment 133 storm drainage, roads, sidewallr% storm sewers, lighting and other services 829 transportation - works yards, vehicles and equipment 177 transportation - transit 44 parks - parkland acquisition 342 parks - parkland development 708 major recreational facilities - major indoor recreational facilities 743 library - library facilities 197 library - library materials 122 electrical distribution services and facilities 563 total $4,337 2. ENGINEERING DRAWING INSPECTION FEE PAYABLE The amount of the Engineering Drawing Inspection Fee payable for this project is $980. 3. DEVELOPMENT AGREEMENT PROCESSING FEE PAYABLE The amount of the Development Agreement Processing Fee payable for this Agreement is $1,200 plus $84 GST. -19- SPECIFIC PROVISlObiS It~vl~EL-I~IG DEVI!I~PMEI~ (Section 27) 1. EXPECTED NLIMBER OF DWELLINGS (1) This Agreement has been entered into in the expectation that 28 dwellings are to be constructed on the Lands, four dwellings on each of: (a) the parcel comprised of Pan 1, Plan 40R-14939; (b) the parcel comprised of Pan 2, Plan 40R-14939; (c) the parcel comprised of Pan 3, Plan 40R-14939; (d) the parcel comprised of Pans 4 and 5, Plan 40R-14939; (e) the parcel comprised of Pans 20, 23 and 34, Plan 40R- 14939; (f) the parcel comprised of Pans 21 and 33, Plan 40R-14939; (g) the parcel comprised of Blocks 53 and 54, Plan 40M-1507, Picketing, and Pans 22, 29, 30, 31 and 32, Plan 40R-14939. (2) If more or less than 28 dwellings are to be constructed in this project, the Town at its sole discretion may require the Owner to obtain new approvals and authorizations under this Agreement and may prohibit any development until the new approvals and authorizations are obtained. - 20 -