HomeMy WebLinkAboutBy-law 4524/94 THE CORPORATION OF THE TOWN OF PICKERING
BY-LAW NO, 4.524/94
Being a by-law to authorize the execution of a
Development Agreement and related documentation
respecting the development of part Block 5, Plan 40M-
1326, Pickering (Parts ! to 8, Plan 40R-15836).
[Kenneth Hollinger; LD47/94 and LD48/94].
WHEREAS a proposal by Kenneth Hollinger to sever part of Block 5, Plan 40M-1326, Picketing, into
four building lots has been approved by the Durham Land Division Committee in its Decisions LD
47/94 and LD 48/94 (March 14, 1994), subject to several conditions, one of which can be satisfied by
the entering into of a satisfactory Development Agreement with The Corporation of the Town of
Pickering, pursuant to the provisions of the Planning Act, R.S.O. 1990, chapter P.13 section 51(6) and
WHEREAS, pursuant to the provision of the Municipal Act, R.S.O. 1990, chapter M.45, section 191(1)
the Council of The Corporation of the Town of Pickering may pass by-laws for acquiring any land or
interest therein for the purposes of the corporation;
NOW THEREFORE, the Council of The Corporation of the Town of Pickering HEREBY ENACTS AS
FOLLOWS:
1. (a) The Mayor and Clerk are hereby authorized to execute a Development Agreement in the
form attached hereto as Schedule A, between Kenneth Hollinger and The Corporation of
the Town of Pickering, respecting the development of part of Block 5, Plan 40M-1326,
Pickering, being Parts 1 to 8, both inclusive, Plan 40R-15836.
(b) The Corporation of the Town of Pickering shall acquire those lands or interests in the
lands referred to in section 32 and identified in Schedule A of that Development
Agreement subject to the terms and conditions and for the purposes set out therein.
2. The Mayor and Clerk are hereby authorized to execute Transfers/Deeds of Easement in the form
attached hereto as Schedule B, effecting the acquisition by The Corporation of the Town of
Picketing of any interests in the nature of storm drainage works easements pursuant to the
provisions of the Development Agreement referred to in section 1, above.
BY-LAW read a first, second and third time and finally passed this 17th day of October, 1994.
..... Wayne , May~
~~ ~'~ l~uce Taylor, Clerk
-59405 '-I
$Cl-IE~ A
THIS DEVELOPMENT AGREEMENT made October 17, 1994, pursuant to the provisions of section 51 of the
Planning Act, R.S.O. 1990, chapter P.13,
BETWEEN:
KENNETH HOLLINGER.
herein called the "Owner"
OF THE FIRST PART,
THE CORPORATION OF THE TOWN OF PICKERING
herein called the "Town"
OF THE SECOND PART.
WHEREAS the Owner proposes to sever part of Block 5, Plan 40M-1326, in the Town of Pickering, in the
Regional Municipality of Durham, and is required as a condition of the approval thereof by the Durham Land
Division Committee in its decisions LD 47/94 and LD 48/94 to enter into an agreement with the Town pursuant
to section 51 of the PlanningAcl, R.S.O. 1990, chapter P.13;
NOW THEREFORE, THIS AGREEMENT WITNESSETH THAT, in consideration of the Town issuing its
clearance of the conditions imposed by the Durham Land Division Committee in its decisions LD 47/94 and LD
48/94, and the covenants hereinafter expressed, the Parties hereto covenant and agree one with the other as
follows:
PART I - INTERPRETING AND APPLYING THIS AGREEMENT
The lands affected by this Agreement (the "Lands") are those parts of Block 5, Plan 40M-1326,
Pickering, designated as Parts 1,2, 3, 4, 5, 6, 7 and 8, Plan 40R-15836, Pickering.
2. STATUS OF THIS AGREEMENT
This Agreement is entered into and executed by the Owner for the purpose of having the Town act in
reliance on the covenants by the Owner contained herein and the Owner hereby waives any right or
claim which it now has or may hereinafter acquire which is inconsistent with the terms of this
Agreement.
(1) Whenever in this Agreement the pronoun "it" is used, it shall be read and construed as "he",
"she", "they", "him", "her" or "them", and the number of the verb agreeing therewith shall be
construed accordingly.
(2) Schedules A, B and C attached hereto shall form part of this Agreement.
(3) Time shall be of the essence of this Agreement.
4. ~2DJi~t .P~MLTZ~
This Agreement shall be enforceable by and against the Parties hereto, their heirs, executors,
administrators, successors and assigns, and the Agreement and all the covenants by the Owner contained
herein shall run with the Lands for the benefit of the Town and the land or interests in land owned by the
Town upon the registration of the Agreement.
(1) Any notice required to be given hereunder may be given by personal delivery or registered mail,
(a) in the case of the Owner, to
Kenneth Hollinger
Post Office Box 356
Pickering, Ontario
LIV 2R6
and
(b) in the case of the Town, to
The Town Clerk
The Corporation of the Town of Picketing
Picketing Civic Complex
One The Esplanade
Pickering, Ontario
LIV 6K7
(2) Each Party may redesignate the person or the address, or both, to whom or to which such notice
may be given by giving written notice to the other.
(3) Any notice given in accordance with this section shall be deemed to have been given on the
second day following the day of delivery or the day of mailing, as the case may be.
The Owner shall retain a licence from any subsequent purchaser of the Lands, or any part thereof, to
enable the Owner and the Town's inspectors to enter upon the Lands in order to comply with the
provisions of this Agreement.
7. OWNER'S GENERAL UNDERTAKING
The Owner shall complete in a good workmanlike manner for the Town, all the municipal services as
hereinafter set forth to the satisfaction of the Town, and shall complete, perform or make payment for
such other matters as may be provided for herein.
Every provision of this Agreement by which the Owner is obligated in any way shall be deemed to
include the words "at the expense of the Owner and at no expense to the Town" unless the context
requires otherwise.
2
PART 2 - CONSTRUCTING THE TOWN'S SERVICES
9. CONSULTING ENGINEERS
(1) The Owner shall retain a Professional Engineer as the Consulting Engineer of the Owner to carry
out all the necessary engineering and to supervise the work required to be done for the
development and construction of the project.
(2) Such Consulting Engineer, or any successor thereto, shall continue to be retained until the work
required to be done for the development and construction of the project is completed and
formally accepted by the Town.
(3) The Owner may change from one Consulting Engineer to another at any time or times during the
development and construction of the project, so long as the Owner has a Consulting Engineer
retained at all times.
10. CONSTRUCTION / INSTALLATION OF TOWN WORKS AND SERVICES
(1) The Owner shall obtain all required approvals and shall construct or install to Town standards
and shall provide to the Town, complete in every detail, the following Town works and services
(the "Works") as shown on plans submitted by the Owner's Consulting Engineer to the Town and
approved by the Town's Director of Public Works in accordance with the Town's specifications
for such Works:
(a) storm water drainage and management system serving the Lands and those lands outside
the Lands but draining through the Lands, complete with detention or retention facilities,
quality control devices and outlets; and
(b) paved driveway approaches between the curb and sidewalk or, where no sidewalk is to be
provided, between the curb and the lot line.
11. GENERAL REGULATIONS RESPECTING SERVICING
(1) Where the construction or installation of services involves a continuation or extension of existing
services, the Owner shall join into the existing services, including adjustment of grades where
necessary, in a good and workmanlike manner.
(2) The Owner shall not dump nor permit to be dumped any fill or debris on, nor remove or permit to
be removed any fill from, any public lands, other than in the actual construction of Works or
services in the project without the written consent of the authority responsible for such lands.
(3) The Owner shall not burn nor permit to be burned any refuse or debris within the project or
adjacent to it.
(4) The Town's Director of Public Works may have qualitative or quantitative tests made of any
materials which have been or are proposed to be used in the construction or installation of any
Works or services required by this Agreement, and the cost of such tests shall be paid by the
Owner within 30 days of invoices being rendered.
(5) The Owner shall pay, within 30 days of invoices being rendered, the costs of,
(a) relocating any existing services or utilities required to be relocated by the construction or
installation of Works, services, or utilities in the project, and
(b) moving any Works, services or utilities installed in any driveway or so close thereto, in
the opinion of the Town's Director of Public Works, as to interfere with the use of the
driveway.
(6) Unless otherwise provided herein, the Owner shall perform any work required to be done under
this Agreement to the specifications of the Town in effect at the date hereof.
(7) The Owner shall provide and erect temporary signs of such nature and at such locations as
designated by the Town's Director of Public Works.
12. ELECTRICAL SERVICES
Where electricity, cable television service or telephone service is to be provided to any lot in the project,
it shall be provided underground and in accordance with the standards and specifications of Picketing
Hydro-Electric Commission, Trillium Cable T.V. Limited or Bell Canada, as the case may be.
13. GRADING CONTROL PLAN / LOT DRAINAGE AND SODDING
(1) The Owner shall submit to the Town, for the approval of the Town's Director of Public Works, a
Grading Control Plan (including a geotechnical soils analysis) prepared by the Owner's
Consulting Engineer, establishing the proposed grading of the Lands to provide for the proper
drainage thereof and the drainage of all adjacent lands which drain through the Lands.
(2) The Grading Control Plan shall be prepared in accordance with the Town's Lot Drainage
Specifications and shall not provide for the drainage of surface run-off water onto Town-owned
parkland, open space or walkways unless provision is made for the installation by the Owner, at
no cost to the Town, of suitable swales and catch basins to manage adequately, in the opinion of
the Town's Director of Parks and Facilities, that surface run-offwater.
(3) The Owner shall grade all the lands in the project in accordance with the approved Grading
Control Plan, ensuring that sufficient topsoil remains as cover on all areas of the project intended
for sodding, seeding, or other planting.
(4) If the Town determines that,
(a) grading has not been done in accordance with the Grading Control Plan,
(b) grading has been done in accordance with the Grading Control Plan but drainage
problems remain, or
(c) sufficient topsoil has not been left in the appropriate areas,
the Owner shall re-grade the project, or part thereof affected, adding a sufficient amount of
topsoil if necessary, or construct catch basins, swales or other structures as may be necessary to
correct such problems, as directed by the Town's Director of Public Works.
(5) The Owner shall sod the front, side and rear yards of each of the residential lots in the project
except for paved, planted or treed areas prior to the occupancy of the dwelling unit located
thereon or within the six months immediately thereal~er except, where the occupancy of the
dwelling unit occurs in November or December of any year, the time limit for sodding may be
extended to June 30 in the following year.
14. AUTHORIZATION TO COMMENCE WORK
The Owner shall not commence the construction or installation of any of the Works without the written
Authorization to Commence Work of the Town's Director of Public Works, which Authorization shall
not be issued until all approvals required by this Agreement have been obtained and,
(a) four red-lined copies of this Agreement executed by the Owner and all Encumbrancers have been
provided to the Town to the satisfaction of the Town Solicitor;
4
(b) all monies, securities and insurance policies, as noted in this Agreement, have been delivered to
the Town to the satisfaction of the Town Treasurer and the Town Solicitor;
(c) all approvals and permits have been obtained by the Owner from the Ministry of the
Environment, the Ministry of Natural Resources and the Metropolitan Toronto and Region
Conservation Authority, or a certificate has been provided by the Owner's Consulting Engineer
that no such approvals or permits are required; and
(d) three executed copies, in a form suitable for registration, of any Transfers/Deeds required by
section 32 respecting the conveyances identified in Schedule A have been provided to the Town
in registrable form to the satisfaction of the Town Solicitor.
15. USE OF WORKS PENDING COMPLETION / EMERGENCY REPAIRS
(1) Any of the Works may be used by the Town, or by such other person or agency as may be
authorized by the Town's Director of Public Works, for the purposes for which the Works are
designed, and such use shall not be deemed an acceptance of any of the Works by the Town, nor
an assumption by the Town of any liability in connection therewith, nor a release of the Owner
from any of its obligations under this Agreement.
(2) The Town may make emergency repairs at any time to any of the Works and may for this purpose
enter the Lands at any time; such repair or entry shall not be deemed an acceptance of any of the
Works by the Town, nor an assumption by the Town of any liability in connection therewith, nor
a release of the Owner from any of its obligations under this Agreement.
16. EXTERNAL ROAD MAINTENANCE AND REPAIR / SNOW PLOWING
(1) Throughout the term of this Agreement, the Owner shall,
(a) maintain all Town roads adjacent to the Lands in a mud and dust free condition and free
of obstructions, regardless of the source or cause of any mud, dust or obstruction; and
(b) repair all Town roads adjacent to the Lands, including boulevards, where damage has
occurred as a result of an operation or operations related in any way to the development
of the project, including the construction of dwelling units therein.
(2) The Owner, within 24 hours of verbal notification by the Town to it or its representatives, shall
undertake such works as are necessary to maintain or repair any Town road requiring such work
in the opinion of the Town's Director of Public Works or his designate.
17. COMPLETION DATES - TOWN WORKS AND SERVICES
The Owner shall complete the Works and services in accordance with the following time limits:
(a) storm water drainage and management system - one year from date of Authorization to
Commence Work;
(b) paved driveway approaches - prior to the occupancy of any dwelling adjacent thereto,
following the satisfactory completion and testing of all of which, and the approval thereof by the Town,
the Town shall issue to the Owner a Completion Acceptance Certificate.
18. FAILURE TO COMPLETE / IMPROPER PERFORMANCE
(1) If, in the opinion of the Town's Director of Public Works, the Owner is not constructing or
installing the Works or services, or causing them to be constructed or installed, within the
specified time or so that they may be completed within the specified time, or is improperly
performing the Works, or has neglected or abandoned them before completion, or has
unreasonably delayed them so that the terms and conditions of this Agreement are being violated
or executed carelessly or in bad faith, or has neglected or refused to renew or again perform
Works rejected by the Director of Public Works as defective or unsuitable, or has in any other
manner, in the opinion of the Director of Public Works, defaulted in the performance of the terms
and conditions of this Agreement, then the Director may notify the Owner and his surety in
writing of the default or neglect and if the notification be without effect for seven days, then the
Director shall have full authority to make any payment or do any thing, including but not limited
to obtaining materials, tools and machinery and employing persons required for the proper
completion of the Works or services or rectification of the default, at the cost and expense of the
Owner or his surety, or both.
(2) In cases of emergency, in the opinion of the Director of Public Works, such Director may act
without prior notice but the Owner and its surety shall be notified forthwith.
(3) The cost of rectifying the default shall be calculated by the Director of Public Works, whose
decision shall be final, and may be charged to the Owner, together with a 25 per cent engineering
and administration fee, by drawing upon the letter of credit filed with the Town under section 20.
19. GUARANTEE OF WORKS. WORKMANSHIP AND MATERIALS
(1) The Owner shall guarantee all Works, services, workmanship and materials employed or used in
the construction, installation or completion of Works, services and other requirements under this
Agreement for a minimum period of two years (the "maintenance period") following the issuance
of the Completion Acceptance Certificate by the Town.
(2) Despite any other provisions of this Agreement, the responsibilities of the Owner during the
maintenance period shall include the maintenance of the Works and services, including the
rectification of any unsatisfactorily installed Works or services.
(3) Prior to the end of the maintenance period, the Owner's Consulting Engineer shall submit to the
Town "as built" construction drawings for the Works and services complete as per To~vn
standards, together with that Consulting Engineer's certificate that those drawings accurately
depict the Works and services as constructed.
(4) Prior to the end of the maintenance period, the Town will re-inspect the Work and services and
if,
(a) the Works and services are acceptable; and
Co) the Owner has performed all of its obligations under the terms of this Agreement to the
satisfaction of the Town,
the Town will issue to the Owner a Final Acceptance Certificate at which time the Town will
assume ownership of the Works and services and the operation and maintenance thereof, and the
maintenance period will then end.
(5) If upon the re-inspection conducted prior to the end of the maintenance period,
(a) the Works and services are not acceptable, or
(b) the Owner has not performed all of its obligations under the terms of this Agreement to
the satisfaction of the Town,
6
the Town will advise the Owner of the deficiencies, the expected rectifications, and the time
limited for implementing the rectifications (the "rectification period") and the maintenance
period shall be extended to the end of the rectification period.
(6) At the end of the rectification period, the Town will re-inspect the Works and services and if,
(a) the Works and services are acceptable; and
(b) the Owner has performed all of its obligations under the terms of this Agreement to the
satisfaction of the Town,
the Town will issue to the Owner a Final Acceptance Certificate at which time the Town will
assume ownership of the Works and services and the operation and maintenance thereof, and the
maintenance period will then end.
(7) If upon the re-inspection conducted at the end of the rectification period,
(a) the Works and services are still not acceptable, or
(b) the Owner has not performed all of its obligations under the terms of this Agreement to
the satisfaction of the Town,
the Town's Director of Public Works shall determine, in his sole discretion, whether a further
rectification period will be granted, and, if so, upon what terms and conditions, or whether the
Town shall proceed under the provisions of section 18, or both.
20. PERFORMANCE AND MAINTENANCE SECURITY
(1) Before this Agreement will be executed by the Town, the Owner shall file with the Town an
irrevocable letter of credit, issued by a chartered bank in Canada in the form set out in Schedule
B and in an amount established by the Director of Public Works (the "original value"), as a
performance and maintenance security for the purpose of,
(a) guaranteeing the satisfactory construction, installation or performance of the Works and
services;
(b) guaranteeing the payment of any mounts payable to the Town under this Agreement;
(c) guaranteeing the payment of any amount that the Town may be required to pay under the
provisions of the Construction Lien Act, or any successor thereto, and
(d) guaranteeing all Works, services, workmanship and materials during the maintenance
period and any rectification period or periods and until a Final Acceptance Certificate has
been issued by the Town's Director of Public Works.
(2) The Owner may, at any time after the first 50 per cent, in value, of Works and services have been
constructed, installed or performed, and paid for, apply for a reduction in the security and such
application shall be made to the Town Treasurer.
(3) Upon written verification from the Director of Public Works that the construction, installation or
performance of the Works for which reduction is being sought have been satisfactorily completed
and paid for, the Town Manager may reduce the amount of the security to an amount not less
than,
(a) 60 per cent of the original value where no certificate or declaration of substantial
performance has been made;
(b) 35 per cent of the original value where,
(i) a certificate or declaration of substantial performance has been published;
(ii) 45 days following such publication have expired; and
(iii) all liens that may be claimed against any holdback required to be retained by the
Town have expired or have been satisfied, discharged or provided for by payment
into court;
and
(c) 17 per cent of the original value where,
(i) a certificate of final completion has been made by the Owner's Consulting
Engineer;
(ii) 45 days following the making of such certificate have expired;
(iii) all liens that may be claimed against any holdback required to be retained by the
Town have expired or have been satisfied, discharged or provided for by payment
into court; and
(iv) a Completion Acceptance Certificate has been issued by the Town's Director of
Public Works,
which 17 per cent portion shall secure the guarantee of Works, workmanship and
materials, until a Final Acceptance Certificate has been issued by the Town's Director of
Public Works, when the balance of the security shall be returned to the Owner subject to
any deductions for rectification of deficiencies.
(4) Upon the approval, if any, of a reduction in the amount of the security required to be provided in
subsection (1), the Town Manager or the Town Treasurer shall provide to the Owner any
necessary assurance to effect the reduction.
21. OWNER'S GENERAL INDEMNITY
Until the Town's Director of Public Works has issued the Final Acceptance Certificate for the Work~ aad
services, the Owner shall indemnify the Town against all actions, causes of actions, suits, claims and
demands whatsoever, which may arise either directly or indirectly by reason of the Owner undertaking
the project or servicing the Lands as required under this Agreement.
22. OCCUPATIONAL HEALTH AND SAFETY
(1) The Owner certifies that it is aware of its duties and obligations under the Occupational Health
and Safety ~tct, or any successor thereto, and all Regulations thereunder (in this section called the
"Act"), and shall ensure that its employees, contractors, subcontractors and their employees,
(a) are aware of their respective duties and obligations under the Act, and
Co) have sufficient knowledge and training to perform all works and services required
pursuant to this Agreement safely and in compliance with the Act.
(2) In the performance of all works and services required pursuant to this Agreement, the Owner
shall,
(a) act safely and comply in all respects with the Act, and
(b) ensure that its employees, contractors, subcontractors and their employees act safely and
comply in all respects with the Act.
8
(3) The Owner shall rectify any unsafe act or practice and any non-compliance with the Act
immediately upon being notified by any person of the existence of such act, practice or non-
compliance.
(4) The Owner shall permit representatives of the Town on the site where any works or services
required pursuant to this Agreement are being performed at any time or times for the purpose of
inspection to determine compliance with this section.
(5) No act or omission by the Town or any representative of the Town (including the entering into of
this Agreement) shall be deemed to be an assumption of any of the duties or obligations of the
Owner, its employees, contractors, subcontractors and their employees under the Act.
(6) In addition to the Owner's general indemnification of the Town pursuant to section 22, above, the
Owner shall indemnify and save harmless the Town,
(a) from any loss, inconvenience, damage or cost to the Town which may result from the
Owner or any of its employees, contractors, subcontractors and their employees failing to
act safely or to comply in all respects with the Act in the performance of any work or
service required pursuant to this Agreement; and
(b) against any action or claim, or costs related thereto, brought against the Town by any
person arising out of any unsafe act or practice or any non-compliance with the Act by the
Owner or any of its employees, contractors, subcontractors and their employees in the
performance of any work or service required pursuant to this Agreement.
23. LIABILITY INSURANCE POLICY / PROVISION FOR DEDUCTIBLE
(1) Before this Agreement will be executed by the Town, the Owner shall file with the Town a
Certificate of Insurance verifying that a Liability Insurance Policy is in effect, setting out the
essential terms and conditions of the insurance, and naming the Town as additional named
insured, all of which shall be subject to the approval of the Town Solicitor.
(2) The policy shall comply with the following provisions:
(a) the minimum limit per occurrence shall be $5,000,000 all inclusive for property damage
and personal liability;
(b) it shall not contain a clause for exclusion for blasting; and
(c) it may not be cancelled unless prior notice by registered letter has been given to the Town
by the insurer thirty days in advance of the expiry date.
(3) The policy premium must be paid initially for a period of one year and the policy shall be
renewed for further one year periods until the Final Acceptance Certificate has been issued by the
Town's Director of Public Works.
(4) If the policy coverage is subject to a deductible amount, the Owner shall file with the Town,
when filing the Certificate of Insurance, a certified cheque or letter of credit with the Town in the
deductible amount, as a deposit, together with a letter from the Owner authorizing the Town to
appoint an independent adjuster and to investigate claims less than the deductible amount and
authorizing the Town to pay such claims deemed valid by the adjuster out of the deposit; the
Owner shall be responsible for all adjustment service costs and shall maintain the deposit
throughout the term of this agreement in the amount of the deductible.
(5) The provision of the insurance policy required by this section shall not relieve the Owner from
liability for claims not covered by the policy or which exceed its limits, if any, for which the
Owner may be held responsible.
9
PART 3 - DEVELOPING THE PROJECT
24. CONSTRUCTION AND OCCUPANCY OF BUILDINGS
(1) No building permit shall be issued for any building or part of a building on the Lands until,
(a) sewer and water facilities are available, and in the opinion of the Town's Director of
Public Works, capable of providing adequate service;
(b) an asphalt base has been laid on the road immediately in front of the building or part
thereof and extended to an existing maintained road; and
(c) the Owner has paid to the Town the applicable development charge for each dwelling in
that building or part thereof in accordance with By-law 3854/91, enacted pursuant to the
Development Charges Act.
(2) No building or part of a building on the Lands shall be occupied except upon the issuance of a
municipal occupancy permit.
(3) No application for a municipal occupancy permit for a building or part of a building shall be
made except upon the following conditions:
(a) storm sewer, sanitary sewer and water facilities are installed and in operation to
adequately serve such building or part thereof;
(b) electric service is completed and in operation; and
(c) such curbs, as in the opinion of the Town's Director of Public Works, are required to be
completed prior to occupancy have been constructed on the road immediately in front of
the building or part thereof and extended to an existing maintained public road.
(4) The Owner shall maintain vehicular access to all occupied buildings on the Lands until the road
adjacent to the Lands is formally assumed by the Town.
25. DESIGN PLANNING - RESIDENTIAL UNITS AND NOISE ATTENUATION STRUCTURES
(1) Prior to the issuance of each building permit for the construction of a residential unit on the
Lands, the Owner shall submit to the Town's Director of Planning, for approval, site plans and
architectural drawings for that unit.
(2) Those plans and drawings may be required, at the Director's option, to provide the following
information:
(a) the location of all buildings and structures to be erected and the location of all facilities
and works associated therewith;
(b) the location of landscaping features, including trees to be preserved;
(c) streetscape for front, rear and flankage elevations at a scale acceptable to the Director;
(d) streetscape to show all street furniture and vegetation;
(e) the relationship of buildings by blocks; and
(f) any other data or information reasonably required.
10
PART 4 - FINANCIAL MATTERS
26. EXPIRY OF SECURITIES
(1) Should any letter of credit security required to be provided hereunder expire before the Town
releases the Owner from the terms and conditions hereof, the Owner shall provide to the Town at
least 30 days in advance of the expiry date of that security, a further security to take effect upon
the expiry.
(2) Such further security shall be in a form and amount satisfactory to the Town.
(3) Should no such further security be provided as required, then the Town shall have the right to
convert the expiring security into cash and hold the cash in lieu of and for the same purposes as
the expiring security.
27. PAYMENT OF LIENS AND OTHER CLAIMS
(1) The Owner shall discharge or vacate any liens or claims filed with the Town or registered on title
to any Town-owned lands within thirty days of being requested to do so by the Town.
(2) At the end of the maintenance period, as extended during any rectification period, the Owner
shall file with the Town a Statutory Declaration stating that,
(a) all materials have been supplied and all services and works have been completed in the
project with respect to the construction and installation of Works and other services;
(b) all accounts for work or service performed and materials placed or furnished upon or in
respect of the construction and installation of Works and other services in the project
have been fully paid and satisfied and no person is entitled to claim a lien under the
Construction Lien Act against the Town or any Town-owned land;
(c) there are no judgments or executions filed against the Owner;
(d) nothing is owed by the Owner or claimed against it for unemployment insurance
deductions, income tax deductions, or by way of contribution or assessment under the
Workers' Compensation Act;
(e) the Owner has not made any assignment for the benefit of creditors, nor has any receiving
order been made against it under the Bankruptcy Act, nor has any petition for such an
order been served upon the Owner; and
(f) 45 days have passed since the completion of the construction, installation, and last
rectification of the Works and services.
28. PAYMENT OF INTEREST ON OVERDUE AMOUNTS PAYABLE
The Owner shall pay interest at the rate of 18 per cent per year to the Town on all sams of money
payable hereunder which are not paid on the due dates calculated from such due dates.
29. pAYMENT OF REALTY AND BUSINESS TAXES / LOCAL IMPROVEMENT CHARGES
(1) The Owner shall pay in full as they come due all realty and business taxes assessed against the
Lands or the Owner as required by law from time to time.
(2) Before this Agreement will be executed by the Town, the Owner shall commute and pay to the
Town or to the Regional Municipality of Durham all local improvement charges assessed against
the Lands.
11
30. PAYMENT OF DEVELOPMENT CHARGES
(1) The Owner shall pay development charges for each dwelling unit within the project to the Town,
in accordance with the Development Charges Act and the Town's Development Charges By-law
3854/91.
(2) The amount of the development charge for each dwelling to be erected shall be the amount set
out in Schedule C for that type of dwelling, as adjusted annually in accordance with Schedule C.
31. PAYMENT OF ENGINEERING. LEGAL AND REGISTRATION FEES
(1) Before this Agreement will be executed by the Town, the Owner shall pay by certified cheque to
the Town an Engineering Drawing Inspection Fee in the amount set out in Schedule C for the
examination and inspection done by the Town's Public Works Department in the processing of
the engineering drawings for this project.
(2) Before this Agreement will be executed by the Town, the Owner shall pay by certified cheque to
the Town an Agreement Processing Fee in the amount set out in Schedule C for the preparation
and processing of this Agreement by the Town's Legal Services Department.
(3) The Owner shall pay all registration costs incurred by the Town relating in any way to the
registration of this Agreement, or any other documentation, including transfers, in the Land
Registry Office within 30 days of invoices being rendered.
PART 5 - TRANSFERS AND REGISTRATIONS
32. TRANSFERS OF LANDS OR INTERESTS IN LANDS OR PAYMENTS IN LIEU THEREOF
(1) Upon executing this Agreement, the Owner shall convey or cause to be conveyed to the Town,
free and clear of all encumbrances and at no cost to the Town, all of the lands or interests in lands
identified in Schedule A for the purposes set out therein.
(2) The Owner hereby warrants that, upon such conveyance, neither the title to the lands conv, ycd
nor their physical state and condition shall prevent the Town from lawfully or physically using
the lands for the purposes for which they are being conveyed as set out in Schedule A.
(3) Where none of the lands identified in Schedule A are to be conveyed for parkland purposes, the
Owner shall pay to the Town, before this Agreement will be executed by the Town, an amount
calculated in accordance with the provisions of Schedule A in lieu of a parkland conveyance.
(4) Any Transfer/Deed given pursuant to this Agreement shall be in a form acceptable to the Town
Solicitor and any Transfer/Deed of a storm drainage works easement shall contain the Storm
Drainage Works Easement Schedule set out in Schedule A.
33. CLEARANCE OF TOWN CONDITIONS IMPOSED BY THE DURHAM LAND DIVISION
Before the Town will advise the Durham Land Division Committee that the conditions of severance
imposed by it at the request of the Town have been satisfied, the Owner shall deliver to the Town the
following:
(a) four red-lined copies of this Agreement executed by the Owner and all Encumbrancers;
(b) all monies, securities and insurance required by this Agreement;
12
(c) three executed copies, in a form suitable for registration, of each Transfer/Deed required by
section 32 respecting the conveyances identified in Schedule A, and one copy of each required
reference plan.
34. REGISTRATION OF AGREEMENT
(1) This Agreement shall be registered by the Town in the Land Registry Office for the Land Titles
Division of Durham (No. 40).
(2) The Owner shall give to every purchaser of the Lands or any part of the Lands actual notice of
the existence and the terms of this Agreement and shall include an acknowledgement in any offer
to purchase or other similar document dealing with the Lands, or any pan of them.
(3) The Owner shall indenmify and save harmless the Town from any loss, inconvenience or damage
which may result to the Town from the Owner's failure to comply with subsection (2) and against
any action or claim made against the Town by any person other than the Owner arising out of the
execution by the Town of this Agreement.
(4) The Owner shall execute such further assurances of the rights hereby granted as may be deemed
necessary by the Town.
IN WITNESS WHEREOF the Owner has hereunto affixed his hand and seal and the Town has hereunto affixed
its Corporate Seal attested to by the hands of its authorized officers.
SIGNED, SEALED AND DELIVERED
In the presence of
KENNETH HOLLINGER Seal
THE CORPORATION OF THE TOWN OF PICKERING
Wayne Arthurs, Mayor
Bruce Taylor, Clerk
D9402
I, MARION HOLLINGER, spouse of Kenneth Hollinger, the Owner herein, hereby consent to the execution and
entering into of this Agreement by Kenneth Hollinger, and the registration of this Agreement upon the title to
the Lands affected hereby, and agree to be bound by the terms of this Agreement.
SIGNED, SEALED AND DELIVERED
In the presence of
MARION HOLLINGER Seal
13
TRANSFERS OF LANDS OR INTERESTS IN LANDS OR PAYMENTS IN LIEU THEREOF
(Section 32)
1. CONVEYANCES REQUIRED TO BE MADE TO THE TOWN
Land to be Conveyed purpose Interest to be Conveyed
Part 2, Plan 40R-15836 Storm drainage works Easement
Part 3, Plan 40R-15836 Storm drainage works Easement
Part 6, Plan 40R-15836 Storm drainage works Easement
Part 7, Plan 40R-15836 Storm drainage works Easement
Any other portion of the lands Storm drainage works Easement
determined by the Town's
Director of Public Works
Any lands outside the Lands Storm drainage works Easement
determined by the Town's
Director of Public Works
2. AMOUNT PAYABLE IN LIEU OF PARKLAND CONVEYANCE
The Owner shall pay to the Town prior to the registration of this Agreement the sum of $5,890 in lieu of
a parkland conveyance.
3. STORM DRAINAGE WORKS EASEMENT REFERENCE PLANS
(1) Upon the completion of the construction and installation of the storm drainage works within each
proposed easement shown on any reference plan, the Owner's Consulting Engineer shall advise
the Town's Director of Public Works of the actual location of the works in relation to the
proposed easement, and if the Director is satisfied with the actual location of the works, the
Owner may use that reference plan for the purpose of conveying the easement to the Town.
(2) If the Town's Director of Public Works is not satisfied with the actual location of the works in
relation to the proposed easement, the Owner shall obtain and deliver to the Town a revised
reference plan, and the provisions of subsection (1) and of this subsection will continue to apply.
(3) Where the Town's Director of Public Works determines that the Town requires easements not
specifically referred to in section 1 of this Schedule, the Owner shall obtain and deliver to the
Town one draft copy of each proposed reference plan required to effect the conveyance of the
easements within 30 days of the Town's request to do so, and the provisions of subsections (1)
and (2) will apply.
4. STORM DRAINAGE WORKS EASEMENT SCHEDULE
Where a conveyance of an easement is for storm drainage works purposes, the following Schedule shall
be attached to the Transfer/Deed of Easement:
14
(7) INTEREST/ESTATE TRANSFERRED
Subject to the following terms and conditions, the free, uninterrupted and unobstructed right and
easement to lay, construct, operate, maintain, inspect, alter, repair, replace, reconstruct and remove storm
drainage works together with appurtenances thereto (herein called the "works"), in, over, along, across,
upon and under the land described in Box 5 (herein called the "lands"), and to drain storm water in, over,
along, across, upon and under the lands, together with the right to the Transferee, its servants, agents and
contractors with all necessary vehicles, supplies and equipment to enter onto the lands and pass and
repass over the lands for the purpose of exercising or enjoying any of the rights granted herein.
The terms and conditions which the parties hereto covenant and agree to observe and be bound by are as
follows:
1. The Transferee shall, except in case of emergency, before commencing any work authorized
hereby, give to the Transferor forty-eight hours previous written notice thereof, and in cases of
emergency such previous notice thereof as is reasonably possible.
2. Upon completion of any work, the Transferee shall fill in all excavations, restore fences, and
restore the surface of the ground by restoring all topsoil and grass cover disturbed thereby, and do
necessary grading to ensure soil and slope stability, and remove all equipment.
3. The Transferor shall not erect any building or structure (except a fence) on the lands, and shall
not place or remove any fill on or from any part of the lands without the previous written consent
of the Transferee.
4. The right and easement granted herein shall be subject to all leases, licences, and any rights of
use or occupation existing at the date hereof, and the Transferor may from time to time renew or
extend these or make new ones, so long as they do not interfere unreasonably with the right and
easement herein granted.
5. The Transferor hereby releases the Transferee from any claim which may arise out of the exercise
by the Transferee of the right and easement granted hereby or which may arise out of the
existence of the storm water or the existence, operation or non-operation of the storm drainage
works provided the Transferee has complied with all of the terms and conditions herein.
6. The Transferor shall execute such further assurances of the fight and easement granted hereby as
the Transferee may reasonably request in writing.
7. The burden of this Transfer and of all the terms and conditions contained herein shall run with
the lands.
8. This Transfer and all of the terms and conditions contained herein shall enure to the benefit of
and be binding upon the Transferor and the Transferee and their respective heirs, executors,
administrators, successors and assigns.
LAND BENEFITTED (DOMINANT TENEMENT)
9. The benefit of this Transfer and all of the terms and conditions contained herein shall run with all
other lands and interests in lands owned, occupied or used by the Transferee for the purpose of
operating and maintaining storm drainage works.
15
REQUIRED FORM FOR PERFORMANCE AND MAINTENANCE SECURITY LETTER OF CREDIT
(Section 20)
To: The Corporation of the Town of Picketing
Picketing Civic Centre
One The Esplanade
Picketing, Ontario
LIV 6K7
We hereby authorize you to draw on [name of bank], ]address of bank], for account of ]name of company or
companies obtaining seeurityl up to an aggregate amount of lamount of security in figures and in fulll
available by drafts at sight for 100% of demand as follows:
Pursuant to the request of our customers(s), the said ]name of company or companies obtaining security], we
Iname of bank], [address of bank], hereby establish and give to you an irrevocable Letter of Credit in your
favour in the total amount of [amount of security in numbers and in words] which may be drawn on by you
at any time and from time to time upon written demand for payment made upon us by you which demand we
shall honour without enquiring whether you have a right as between yourself and our said customer(s or any of
them) to make such demand, and without recognizing any claim of our said customer(s or any of them).
Provided, however, that you are to deliver to Iname of bankl, ]address of bank], at such time as a written
demand for payment is made upon us a certificate signed by you agreeing or confirming that monies drawn
pursuant to this Letter of Credit are payable to you or are to be or have been expended pursuant to obligations
incurred or to be incurred by you with reference to your file regarding a Development Agreement dated [date of
Agreementl, between Iname of signatories to Agreement, other than Town and Encumbrancer(s)l and The
Corporation of the Town of Picketing; this Letter of Credit is given as the Performance and Maintenance
Security required by section 20 of that Agreement.
Partial drawings are permitted.
The amount of this Letter of Credit shall be reduced from time to time as advised by notice in writing given to
us from time to time by you.
This Letter of Credit will continue up to and including [date of expiry of Letter of Creditl and will expire on
that date and you may call for payment of the full amount outstanding under this Letter of Credit at any time up
to the close of business on that date. It is a condition of this Letter of Credit that it shall be deemed to be
automatically extended for one year from the present or any future expiration date hereof, unless thirty days
prior to any such date, we shall notify you in writing by registered mail that we elect not to consider this Letter
of Credit renewed for any such additional period.
We hereby covenant with drawers, endorsers, and bona fide holders of drafts drawn under and in accordance
with the terms of this credit that such drafts will be duly honoured if drawn and negotiated on or before Idate of
expiry of Letter of Credit].
The drafts drawn under this credit are to be endorsed hereon and shall slate on their face that they are drawn
under [name of bankI, [address of bank].
DATED this day of ,19
Instructions for completing Letter of Credit:
I. Letter of Credit must be typed on bank letterhead.
2. Information required in square brackets must be provided where indicated, without brackets.
3. Phrases shown in round brackets must be included without brackets where there are two or more companies comprising the
customer.
4. The date in the sixth paragraph must be at least one year from the date of the Letter of Credit.
5. The date in the seventh paragraph must be the same as the date in the sixth paragraph.
6. Bank signatories must show name, printed or typed, and title, in addition to signature
16
DEVELOPMENT CHARGES, ENGINEERING AND LEGAL FEES
(Sections 30 and 31 )
I. DEVELOPMENT CHARGES PAYABLE
(1) Until and including October 7, 1995, the amount of the development charge payable under the
Town's Development Charges By-law 3854/91 for each single or semi-detached dwelling within
this project is $5,380.
(2) From and a~er October 8, 1995, the amount of the development charge payable for dwelling
units within this project will be as set out in subsection (1) as adjusted on October 8, 1995, and
annually on every October 8 thereafter until they are paid, in accordance with the Engineering
News Record Cost Index (Toronto).
2. ENGINEERING DRAWING INSPECTION FEE PAYABLE
The amount of the Engineering Drawing Inspection Fee payable for this project is $140.
3. DEVELOPMENT AGREEMENT PROCESSING FEE PAYABLE
The amount of the Agreement Processing Fee payable for this Agreement is $1,284 [$1,200 plus $84
GST.]
17
Transfer/Deed of Land
Form I -- Land Regletratlon Reform Act
(1) Regllt~ ~] Land Tltlel [] 2) Page 1 of pages
(3) Pro~ert~ Block Property
I~e~ltlfler(i) Add~honal
see C
(4) Conelde~atlon
Dollars $
Division [] Consohdatlon []
New Properly Identihers
Executions
[6) This (a) Redescnption ! (b) Schedule for (7) Intar~UEitata Tmneterred
Document New Easement Addihonal Fee Simp e
Contains Plan/Sketch [] Description [] Parties [] Other []
(8) Trensferor~s) The transferor hereby transfers lhe land to the transferee and certifies that the transferor ~s at least e~ghteen years old and that
Date of Signature
Name(s) Signature(s)
'(9) Spouea(s) of Transferor(s) I hereby consent to thru transacbon Date of S~gnature
Name(s) S~gnature(s) ¥ M D
(10) Trenffe~'or(s) Address
for Service
11) Transferee(s) Date of B~rth
Bruce ?aylor,
(12) Ttlmsfefee{s) Address
forServ~ce Civic Complex, One The Esplanade, Pickering, Ontario LiV 6K7
> <
(13) Tranelaror(a) The ~ransferor verifies thai Id Ihe Des[ el the lransferor's knowledge and behel, th,s transfe~ does riel contravene aachen 50 of Ihe Plann,ng Act
Date of Signature Date of S~gnature
~ Solicitor for Transferor(m) I have explained ~he e~ecl of sechon §0 of ~he Planning Act Id the trar~sleror and I have made ~nqu,r~es et Ihe transfero~ Id
Z} bahai. Ibis transfer does not Contravene lhal section I am a~ Ontario sohc~[or ~n good standing Date of Signature
M
D
~u Addressandof ,
O Solicitor Signature .......................... , ...... , .... :...
I ~ I (14) Solicitor for Traneferaets~ i have ,nvesh~aled t~e t,~le ~o Ih,s ~and a~d ~o aSu~,ng land where relevasl and I am sat,shed thal the Idle records
( I~ ~-I reveal no conlravent,on a~ ~e~ dUI ,n subcl~use 50 (22) (c) 0') of t~e Planning Act and ~hal to fha best el my knowledge eno behef th,s Iransfer
· . I~,~ ~ ~ I Name and Date of S~gnature
(15) A~menl Roll Number Ch, ! Mun i Map ' Sue Par. ~l ~ Fees and Tax
of Fro~ert~ ;
, Registrahon Fee
>(16) Municipal Address of Properly ~ (17) Document Prepar~¢l by:
TownC .M. TimothYsolicitorSheffield ! lLand Transler Tax
Town of Pickering -
One The Espl~narl~
·Pickering, Ontario L1V 6K7 , ~l/ ~ .,
o, Schedule
Fo~t S -- Lind RegbtrMlcfl Refrain Act,
~' AddltlCN'tld Pro~mr~f Idenllf~r(i) ind/o~ Othm' Informllion
(7) INTEREST/ESTATE TRANSFERRED
Subject to the following terms and conditions, the free, uninterrupted and unobstructed right
and easement to lay, construct, operate, maintain, inspect, alter, repair, replace, reconstruct and
remove storm drainage works together with appurtenances thereto (herein. called the 'works"),
in, over, along, across, upon and under the landdescribed in Box 5 (hereto called the "lands"),
and to drain storm water in, over, 'along, across, upon and under the lands, together with the
right to the Transferee, its servants, agents and contractors with all necessary vehicles, supplies
and equipmcnt to enter onto thc lands and pass and repass over the lands for the puspose of
exercising or enjoying any of thc rights granted herein.
Thc terms and conditions which the parties hereto covenant .,id agree to observe and he bound
by are as follows:
1. The Transferee shall, except in case of emergency, before commencing any work
authorized hereby, give to the Transferor forty-eight hours previous wriucn notice
thereof, and in cases of emergency such previous notice thereof as is reasonably possible.
2. Upon completion of any work, the Transferee shall fill in all excavations, restore fences,
and restore the surface of thc ground by restoring all topsoil and grass cover disturbed
thereby, and do necessary grading to ensure soil and slope stability, and remove all
equipment.
3. The Transferor shall not erect any building or structure (except a fence) on the lands, and
shall not place or remove any fill on or from any part of the lands without thc previous
written consent of the Transferee.
4. The right and easement granted herein shall be subject to all leases, licences, and any
rights of use or occupation existing at the date hereof, and the Transferor may from thne
to time renew or extend these or make new ones, so long as they do not interfere
unreasonably with the right and easement herein granted.
5. The Transferor hereby releases the Transferee from any claim which may arise out of the
exercise by thc Transferee of the right and easement granted hereby or which may arise
out of thc existence of thc storm water or thc existence, operation or non-operation of the
storm drainage works provided the Transferee has complied with all of the terms and
conditions herein.
6. The Transferor shall execute such further assurances of the right and easement granted
hereby as the Transferee may reasonably request in writing.
7. The burden of this Transfer and of all tile terms and conditions contained herein shall nm
with the lands.
8. This Transfer and all of tile terms and conditions contained herein shall enure to the
benefit of and be binding upon the Transferor and the Transferee and their respective
heirs, executors, achnhfistrators, successors and assigns.
LAND BENEFITTED (DOMINANT TENEMENT)
9. The benefit of this Transfer and all of the terms and conditions contained herein shall run
with all other lands and interests in lands owned, occupied or usad by the Transferee for
the purpose of operating and maintaining storm drainage works.
OTHI3