HomeMy WebLinkAboutBy-law 4604/95 THE CORPORATION OF THE TOWN OF PICKERING
BY-LAW NO. 4604/95
Being a by-law to authorize the execution of a
Development Agreement and related documentation
respecting the development of Part Lot 12, Plan 282,
Picketing (Parts 4, 5, 6, 7, 8 and 9, Plan 40R-)DEXO00
[A 7/94 - Nick Hatziantoniou and Susan Hatziantoniou].
WHEREAS an application (A7/94) by Nick Hatziantoniou and Susan Hatziantoniou to amend to Zoning
By-law 3036 to provide for the development of six lots, being those parts of Lot 12, Plan 282, Picketing,
designated as Parts 4, 5, 6, 7, 8 and 9, Plan 40R-XXXXX, has been approved by the Council of The
Corporation of the Town of Pickering on condition that Nick Hatziantoniou and Susan Hatziantoniou
enter into a satisfactory Development Agreement with The Corporation of the Town of Pickering,
pursuant to the provisions of the Planning Act, R.S.O. 1990, chapter P. 13 section 51 (6) and
WHEREAS, pursuant to the provision of the Municipal Act, R.S.O. 1990, chapter M.45, section 191 ( 1 )
the Council of The Corporation of the Town of Pickering may pass by-laws for acquiring any land or
interest therein for the purposes of the corporation;
NOW THEREFORE, the Council of The Corporation of the Town of Pickering HEREBY ENACTS AS
FOLLOWS:
1. (a) The Mayor and Clerk are hereby authorized to execute a Development Agreement in the
form attached hereto as Schedule A, between Nick Hatziantoniou and Susan
Hatziantoniou and The Corporation of the Town of Pickering, respecting the development
of part of Lot 12, Plan 282, Pickering, being Parts 4, 5, 6, 7, 8 and 9, Plan 40R-XXXXX.
(b) The Corporation of the Town of Pickering shall acquire those lands or interests in the
lands referred to in section 33 and identified in Schedule A of that DeYelopment
Agreement subject to the terms and conditions and for the purposes set out therein.
2. The Mayor and Clerk are hereby authorized to execute Transfers/Deeds of Easement in the form
attached hereto as Schedule B, effecting the acquisition by The Corporation of the Town of
Pickering of any interests in the nature of storm drainage works easements pursuant to the
provisions of the Development Agreement referred to in section 1, above.
BY-LAW read a first, second and third time and finally passed this 18th day of April, 1995.
TOWN OF' Wayne Artl~, Mav~r
PICKERiNG 1¢;~~
APPROVED
AS TO FORM
Bruce Taylor, Clerk
THIS DEVELOPMENT AGREEMENT made April 18, 1995, pursuant to the provisions of section 51 of the
Planning Act, R.S.O. 1990, chapter P.13,
BETWEEN:
NICK HATZ1ANTONIOU and SUSAN HATZIANTONIOU.
herein collectively called the "Owner"
OF THE FIRST PART,
- and -
THE CORPORATION OF THE TOWN OF PICKERING
herein called the "Town"
OF THE SECOND PART.
WHEREAS the Owner has applied for an amendment (A7/94) to Zoning By-law 3036 to provide for the
development of six lots, being those pans of Lot 12, Plan 282, Picketing, designated as Pans 4, 5, 6, 7, 8 and 9, Plan
40R-XXXXX, and is required as a condition of the approval thereof by the Council of the Town to enter into an
agreement with the Town pursuant to section 51 of the Planning Act, R.S.O. 1990, chapter P.13;
NOW THEREFORE, THIS AGREEMENT WITNESSETH THAT, in consideration of the Council of the Town
enacting the amendment applied for, and of the covenants hereinafter expressed, the Parties hereto covenant and
agree one with the other as follows:
PART I - INTERPRETING AND APPLYING THIS AGREEMENT
The land affected by this Agreement (the "Lands") is that part of Lot 12, Plan 282, Picketing, designated as
Pans 4, 5, 6, 7, 8 and 9, Plan 40R-XXXXX.
2. STATUS OF THIS AGREEMENT
This Agreement is entered into and executed by the Owner for the purpose of having the Town act in
reliance on the covenants by the Owner contained herein and the Owner hereby waives any right or claim
which it now has or may hereinafter acquire which is inconsistent with the terms ofthis Agreement.
3. INTERPRETATION
(1) Whenever in this Agreement the pronoun "it" is used, it shall be read and construed as "he". "she",
"tile)", "him". "her" or "them". and tile number of the verb agreeing therex~ith shall be construed
accordingly.
(2) Schedules A, [:l and C at~ached hereto shall form part of this Agreement.
(3) Tinlc shall be of thc essence of this Agreement.
This Agreement shall be enforceable jointly and severally by and against the Parties hereto, their heirs,
executors, administrators, successors and assigns, and the Agreement and all the covenants by the Owner
contained herein shall run with the Lands for the benefit of the Town and the land or interests in land owned
by the Town upon the registration of this Agreement.
(1) Any notice required to be given hereunder may be given by personal delivery or registered mail,
(a) in the case of the Owner, to either
Nick Hatziantoniou or Susan Hatziantoniou
62 Woodville Avenue
Toronto, Ontario
M4K 2J6
and
(b) in the case of the Town, to
The Town Clerk
The Corporation of the Town of Picketing
Picketing Civic Complex
One The Esplanade
Pickering, Ontario
L1V6K7
(2) Each Party may redesignate the person(s) or the address, or both, to whom or to which such notice
may be given by giving written notice to the other.
(3) Any notice given in accordance with this section shall be deemed to have been given on the second
day following the day of delivery or the day of mailing, as the case may be.
The Owner shall retain a licence from any subsequent purchaser of the Lands, or any part thereof, to enable
the Owner and the Town's inspectors to enter upon the Lands in order to comply with the provisions of this
Agmement.
7. OWNER'S GENERAL UNDERTAKING
The Owner shall complete in a good workmanlike manner for the Town, all the municipal services as
hereinafter set forth to the satisfaction of the Town, and shall complete, perform or make payment for such
other matters as may be provided for herein.
8. OWNER'S EXPENSE
Every provision of this Agreement by ~xhich the Owner is obligated in any x~a3 shall be deemed to include
the words "at the expense of the O~sner and at no expense to the Town" unless the context requires
othcrx~ ise.
PART 2 - CONSTRUCTING THE TOWN'S SERVICES
9. CONSULTING ENGINEERS
(I) The Owner shall retain a Professional Engineer as the Consulting Engineer of the Owner to carry out
all the necessary engineering and to supervise the work required to be done for the development and
construction of the project.
(2) Such Consulting Engineer, or any successor thereto, shall continue to be retained until the work
required to be done for the development and construction of the project is completed and formally
accepted by the Town.
(3) The Owner may change from one Consulting Engineer to another at any time or times during the
development and construction of the project, so long as the Owner has a Consulting Engineer
retained at all times.
! 0. CONSTRUCTION / INSTALLATION OF TOWN WORKS AND SERVICES
(1) The Owner shall obtain all required approvals and shall construct or install to Town standards and
shall provide to the Town, complete in every detail, the following Town works and services (the
"Works") as shown on plans submitted by the Owner's Consulting Engineer to the Town and
approved by the Town's Director of Public Works in accordance with the Town's specifications for
such Works:
(a) connections to street storm sewers on the roads adjacent to the Lands and adjacent to Pan 3,
Plan 40R-XXXXX (whether or not the those roads are separated from the Lands or that Par~
by a reserve or reserves) complete with all appurtenances;
(b) a storm water drainage and management system serving,
(i) the Lands,
(ii) Part 3, Plan 40R-XXXXX, and
(iii) other lands outside the Lands and outside that Part, but which drain through the
Lands or through that Part or through both the Lands and that Part,
complete with delentJon or retention facilities, quality control devices and outlets;
(c) boulevard and sidewalk on the roads referred to in (a); and
(d) street tree planting on the roads referred to in (a).
(2) If at any time prior to the acceptance of the Works, the Town's Director of Public Works is of the
opinion that additional works are necessary to provide adequately any of the public services required
by the project, the Owner shall construct, install or perform such additional works at the request of
the Director.
(3) All Works shall be constructed and installed in accordance with the Town's specifications and in a
good and workmanlike manner under the supervision of the Owner's Consulting Engineer and under
the observation of the Town's inspectors.
(4) The Owner shall conduct video inspections of all underground services required to be constructed or
installed hereby and shall provide a VHS-format :ideotapc record of those inspections to the Tov~n.
(5) Thc Ox~ner shall pa.', to the 'Foxkn the Tox~,n's costs of inspection, including but not necessaril.x
limited It/. salaries ~md xxa~cs of inspectors. ICSlJllg I'cCS and administration fees. xx ithin 30 dax
I I. GENERAL REGULATIONS RESPECTING SERVICING
(1) The construction of Town boulevards shall include the construction of paved driveway approaches
between the curb and sidewalk or, where no sidewalk is to be provided, between the curb and the lot
line.
(2) Where the construction or installation of services involves a continuation or extension of existing
services, the Owner shall join into the existing services, including adjustment of grades where
necessary, in a good and workmanlike manner.
(3) The Owner shall not dump nor permit to be dumped any fill or debris on, nor remove or permit to be
removed any fill from, any public lands, other than in the actual construction of works in the project
without the written consent of the authority responsible for such lands.
(4) The Owner shall not burn nor permit to be burned any refuse or debris within the project or adjacent
to it.
(5) The Town's Director of Public Works may have qualitative or quantitative tests made of any
materials which have been or are proposed to be used in the construction or installation of any
services required by this Agreement, and the cost of such tests shall be paid by the Owner within 30
days of invoices being rendered.
(6) The Owner shall pay, within 30 days of invoices being rendered, the costs of,
(a) relocating any existing services or utilities required to be relocated by the construction or
installation of Works, services, or utilities in the project, and
(b) moving any Works, services or utilities installed in driveways or so close thereto, in the
opinion oftbe Town's Director of Public Works, as to interfere with the use of the driveway.
(7) Unless otherwise provided herein, the Owner shall perform any work required to be done under this
Agreement to the specifications of the Town in effect at the date hereof.
(8) The Owner shall provide and erect temporary signs of such nature and at such locations as
designated by the Town's Director of Public Works.
12. ELECTRICAL SERVICES
Where electricity, cable television service or telephone service is to be provided to any lot or block in the
project, it shall be provided underground and in accordance with the standards and specifications of
Picketing Hydro-Electric Commission, Trillium Cable T.V. Limited or Bell Canada, as the case may be.
13. TREF~NVENTORY / TREE PRESERVATION PROGRAM
(1) The Owner shall submit a Tree Inventory and a Tree Preservation Program prepared by a qualified
expert, and based upon the Town-approved Grading Control Plan, indicating which existing trees in
the project may be preserved to the Town's Director of Public Works for the review and approval of
the Town's Director of Planning and Director of Parks and Facilities, and shall implement the
Program as approved only.
(2) Until the Tree Preservation Program is approved the Owner shall not commence, nor allow to be
commenced, any aspect of the development of the lands in the project, including thc removal of any
tree.
In thc cxcnt that an5 tree required to be prcscrxed bx thc approxcd Tree Prcscrx:Hi,m [h',~uun is
ICll/t~x cd oF is. ~ll thc opini~m of thc Toxxn's I)ircctor of Parks and Facilities. d,lmz~cd lo such afl
cMcnt that its value or longevity is decreased or is likely to be decreased, then thc O~ncr shall
rcl~l;~cc lb:Il IFcc x~il]l 3 ti'cc of a hci~hl, diamclcr mhd spcc[oq dclcrmincd bx thc D[~cch~: ,[~h
(4) The Owner's liability under subsection (3) shall continue until,
(a) where the lands upon which the tree is located comprise a residential building lot, twelve
months after the completion of the sodding on the lot, or
(b) where the lands upon which the tree is located comprise lands other than a residential
building lot, the issuance by the Town of the Final Acceptance Certificate.
14. GRADING CONTROL PLAN / LOT DRAINAGE AND SODDING
(1) The Owner shall submit to the Town, for the approval of the Town's Director of Public Works, a
Grading Control Plan and geotechnical soils analysis prepared by the Owner's Consulting Engineer,
establishing the proposed grading of the lands in the project to provide for the proper drainage
thereof and the drainage of all adjacent lands which drain through the lands in the project.
(2) The Grading Control Plan shall be prepared in accordance with the Town's Lot Drainage
Specifications and shall not provide for the drainage of surface run-off water onto Town-owned land
unless provision is made for the installation by the Owner, at no cost to the Town, of suitable swales
and catch basins to manage adequately, in the opinion of the Town's Director of Parks and Facilities,
that surface run-off water.
(3) The Owner shall grade all the lands in the project in accordance with the approved Grading Control
Plan, ensuring that sufficient topsoil remains as cover on all areas of the project intended for
sodding, seeding, or other planting.
(4) If the Town determines that,
(a) grading has not been done in accordance with the Grading Control Plan,
(b) grading has been done in accordance with the Grading Control Plan but drainage problems
remain, or
(c) sufficient topsoil has not been left in the appropriate areas,
the Owner shall re-grade the project, or part thereof affected, adding a sufficient amount of topsoil if
necessary, or construct catch basins, swales or other structures as may be necessary to correct such
problems, as directed by the Town's Director of Public Works.
15. AUTHORIZATION TO COMME_NCE_ WORK
The Owner shall not commence the construction or installation of any of the Works without the written
Authorization to Commence Work of the Town's Director of Public Works, which Authorization shall not be
issued until all approvals required by this Agreement have been obtained and,
(a) four red-lined copies of this Agreement executed by the Owner and all Encumbrancers have been
provided to the Town to the satisfaction of the Town Solicitor;
(b) all monies, securities and insurance policies, as noted in this Agreement, have been delivered to the
Town to the satisfaction of the Town Treasurer and the Town Solicitor;
(c) all approvals and permits have been obtained by the Owner from the Ministry of the Environment,
the Ministry of Natural Resources and the Metropolitan Toronto and Region Conservation Authority,
or a certificate has been provided by the Owner's Consulting Engineer that no such approvals or
permits are required; and
(d) three executed copies, in a form suitable for registration, of any Transfers/Deeds required by section
33 respecting the conveyances identified in Schedule A have been provided to the Town in
registrable form to the satisfaction of the Town Solicitor.
5
16. USE OF WORKS PENDING COMPLETION / EMERGENCY REPAIRS
(I) Any of the Works may be used by the Town, or by such other person or agency as may be authorized
by the Town's Director of Public Works, for the purposes for which the Works are designed, and
such use shall not be deemed an acceptance of any of the Works by the Town, nor an assumption by
the Town of any liability in connection therewith, nor a release of the Owner from any of its
obligations under this Agreement.
(2) The Town may make emergency repairs at any time to any of the Works and may for this purpose
enter the Lands at any time; such repair or entry shall not be deemed an acceptance of any of the
Works by the Town, nor an assumption by the Town of any liability in connection therewith, nor a
release of the Owner from any of its obligations under this Agreement.
17. ROAD MAINTENANCE AND REPAIR
(I) Throughout the term of this Agreement, the Owner shall,
(a) maintain all Town roads outside the project, including boulevards, in a mud and dust free
condition and free of obstructions, where the source or cause of the mud, dust or obstruction
is an operation or operations related in any way to the development of the project; and
(b) repair all Town roads outside the project, including boulevards, where damage has occurred
as a result of an operation or operations related in any way to the development of the project.
(2) The Owner, within 24 hours of verbal notification by the Town to it or its representatives, shall
undertake such works as are necessary to clean, clear, repair, plow or salt any Town road requiring
such work in the opinion of the Town's Director of Public Works or his designate.
18. COMPLETION DATES - TOWN WORKS AND SERVICES
The Owner shall complete the Works in accordance with the following time limits:
(a) street storm sewer connections - one year from date of Authorization to Commence Work;
(b) storm water drainage and management system - one year from date of Authorization to Commence
Work;
(c) boulevards and sidewalks on adjacent roads - prior to the occupancy of any building on the Lands;
(d) street tree planting o two years from date of Authorization to Commence Work,
following the satisfactory completion and testing of all of which, and the approval thereof by the Town, the
Town shall issue to the Owner a Completion Acceptance Certificate.
19. FAILURE TO COMPLETE / IMPROPER PERFORMANCE
(1) If, in the opinion of the Town's Director of Public Works, the Owner is not constructing or installing
the Works, or causing them to be constructed or installed, within the specified time or so that they
may be completed within the specified time, or is improperly performing the Works, or has
neglected or abandoned them before completion, or has unreasonably delayed them so that the terms
and conditions of this Agreement are being violated or executed carelessly or in bad faith, or has
neglected or refused to renew or again perform Works rejected by the Director of Public Works as
defective or unsuitable, or has in any other manner, in the opinion of the Director of Public Works,
defaulted in the performance of the terms and conditions of this Agreement, then the Director may
notify the Owner and his surety in writing of the default or neglect and if the notification be without
effect for seven days, then the Director shall have full authority to make any payment or do any
thing, including but not limited to obtaining materials, tools and machinery and employing persons
required for the proper completion of the Works or rectification of the default, at the cost and
expense of the Owner or his surety, or both.
6
(2) In cases of emergency, in the opinion of the Director of Public Works, such Director may act without
prior notice but the Owner and its surety shall be notified forthwith.
(3) The cost of rectifying the default shall be calculated by the Director of Public Works, whose
decision shall be final, and may be charged to the Owner, together with a 25 per cent engineering
and administration fee, by drawing upon the letter of credit filed with the Town under section 21.
20. ~UARANTEE OF WORKS. WORKMANSHIP AND MATERIALS
(1) The Owner shall guarantee all Works, workmanship and materials employed or used in the
construction, installation or completion of Works, services and other requirements under this
Agreement for a minimum period of two years (the "maintenance period") following the issuance of
the Completion Acceptance Certificate by the Town.
(2) Despite any other provisions of this Agreement, the responsibilities of the Owner during the
maintenance period shall include the maintenance of the Works, including the rectification of any
unsatisfactorily installed Works.
(3) Prior to the end of the maintenance period, the Owner's Consulting Engineer shall submit to the
Town,
(a) "as built" construction drawings for the Works complete as per Town standards, together
with that Consulting Engineer's certificate that those drawings accurately depict the Works
as constructed; and
(b) a statement by an Ontario Land Surveyor that all standard iron bars as shown on Plan 40R-
XXXXX have been found or m-established.
(4) Prior to the end of the maintenance period, the Town will re-inspect the Works and if,
(a) the Works are acceptable; anti
(b) the Owner has performed all of its obligations under the terms of this Agreement to the
satisfaction of the Town,
the Town will issue to the Owner a Final Acceptance Certificate at which time the To~n will assume
ownership of the Works and the operation and maintenance thereof, and the maintenance period will
then end.
(5) If upon the re-inspection conducted prior to the end of the maintenance period,
(a) the Works are not acceptable, or
(b) the Owner has not performed all of its obligations under the terms of this Agreement to the
satisfaction of the Town,
the Town will advise the Owner of the deficiencies, the expected rectifications, and the time limited
for implementing the rectifications (the "rectification period") and the maintenance period shall be
extended to the end of the rectification period.
(6) At the end of the rectification period, the Town will re-inspect the Works and if.
(a) thc \Vorks arc acceptable: and
(b) thc Ox~ncr bas performed all of its obligations under the terms of this Agrecmcm to thc
satisfi~¢tion ol'the ¥oxx n.
the I'ox~n xxill issue to the ()xxncr a Final Acceptance Certificate at x~hich time the Toxin xtill assume
ox~ nersbip oF the Works and lhc opcralion and mahllcmmcc lhcrcof, and the mainlcn.mcc period x~ ill
IJlcl/
(7) If upon the re-inspection conducted at the end of the rectification period,
(a) the Works are still not acceptable, or
(b) the Owner has not performed all of its obligations under the terms of this Agreement to the
satisfaction of the Town,
the Town's Director of Public Works shall determine, in his sole discretion, whether a l'urther
rectification period will be granted, and, if so, upon what terms and conditions, or whether the Town
shall proceed under the provisions of section 19, or both.
21. P_E_RFORMANCE AND MAINTENANCE SECURITY
(1) Before this Agreement will be executed by the Town, the Owner shall file with the Town an
irrevocable letter of credit, issued by a chartered bank in Canada in the form set out in Schedule B
and in an amount established by the Director of Public Works (the "original value"), as a
performance and maintenance security for the purpose of,
(a) guaranteeing the satisfactory construction, installation or performance of the Works;
(b) guaranteeing the payment of any amounts payable to the Town under this Agreement;
(c) guaranteeing the payment of any amount that the Town may be required to pay under the
provisions of the Construction Lien Act, or any successor thereto, and
(d) guaranteeing all Works, workmanship and materials during the maintenance period and any
rectification period or periods and until a Final Acceptance Certificate has been issued by the
Town's Director of Public Works.
(2) The Owner may, at any time after the first 50 per cent, in value, of Works have been constructed,
installed or performed, and paid for, apply for a reduction in the security and such application shall
be made to the Town Treasurer.
(3) Upon written verification from the Director of Public Works that the construction, installation or
performance of the Works for which reduction is being sought have been satisfactorily completed
and paid for, the Town Manager may reduce the amount of the security to an amount not less than,
(a) 60 per cent of the original value where no certificate or declaration of substantial
performance has been made;
(b) 35 per cent of the original value where,
(i) a certificate or declaration of substantial performance has been published;
(ii) 45 days following such publication have expired; and
(iii) all liens that may be claimed against any holdback required to be retained by the
Town have expired or have been satisfied, discharged or provided for by payment
into court;
and
(c) 17 per cent of the original value where,
(i) a certificate of final completion has been made by the Owner's Consulting Engineer;
(ii) 45 days following the making of such certificate have expired;
(iii) all liens that may be claimed against any holdback required to be retained by the
Town have expired or have been satisfied, discharged or provided for by payment
into court; and
8
(iv) a Completion Acceptance Certificate has been issued by the Town's Director of
Public Works,
which 17 per cent portion shall secure the guarantee of Works, workmanship and materials,
until a Final Acceptance Certificate has been issued by the Town's Director of Public Works,
when the balance of the security shall be returned to the Owner subject to any deductions for
rectification of deficiencies.
(4) Upon the approval, if any, of a reduction in the amount of the security required to be provided in
subsection (I), the Town Manager or the Town Treasurer shall provide to the Owner any necessary
assurance to effect the reduction.
22. OWNER'S GENERAL INDEMNITY
Until the Town's Director of Public Works has issued the Final Acceptance Certificate for the Works, the
Owner shall indemnify the Town against all actions, causes of actions, suits, claims and demands
whatsoever, which may arise either directly or indirectly by reason of the Owner undertaking the project or
servicing the Lands as required under this Agreement.
23. OCCUPATIONAL HEALTH AND SAFETY
(I) The Owner certifies that it is aware of its duties and obligations under the Occupational Health and
Safely Act, or any successor thereto, and all Regulations thereunder (herein called the "Act"), and
shall ensure that its employees, contractors, subcontractors and their employees,
(a) are aware of their respective duties and obligations under the Act, and
(b) have sufficient knowledge and training to perform all works and services required pursuant
to this Agreement safely and in compliance with the Act.
(2) In the performance of all works and services required pursuant to this Agreement, the Owner shall,
(a) act safely and comply in all respects with the Act, and
(b) ensure that its employees, contractors, subcontractors and their employees act safely and
comply in all respects with the Act.
(3) The Owner shall rectify any unsafe act or practice and any non-compliance with the Act
immediately upon being notified by any person of the existence of such act, practice or non-
compliance.
(4) The Owner shall permit representatives of the Town on the site where any works or services required
pursuant to this Agreement are being performed at any time or times for the purpose of inspection to
determine compliance with this section.
(5) No act or omission by the Town or any representative of the Town (including the entering into of
this Agreement) shall be deemed to be an assumption of any of the duties or obligations of the
Owner, its employees, contractors, subcontractors and their employees under the Act~
(6) In addition to the Owner's general indemnification of the Town pursuant to section 22, abo~e, the
Ox~ner shall indemni~' and save harmless the Town,
(a) from any loss, inconvenience, damage or cost to the Tov, n v, hich ma3 result from thc Ox~ner
or an3 of its emplo3ees, conlractors, subcontractors and their cmplo3ees failing to act sat¥13
or to compl? in all ~cspcctb x~ith the Acl ill thc perf~mancc of a% x~o:k ur scr,. icc ~cquhcd
purstmnt to this Agreement: and
9
(b) against any action or claim, or costs related thereto, brought against the Town by any person
arising out of any unsafe act or practice or any non-compliance with the Act by the Owner or
any of its employees, contractors, subcontractors and their employees in the performance of
any work or service required pursuant to this Agreement.
24. LIABILITY INSURANCE POLICY / PROVISION FOR DEDUCTIBLE
(1) Before this Agreement will be executed by the Town, the Owner shall file with the Town a
Certificate of Insurance verifying that a Liability Insurance Policy is in effect, setting out the
essential terms and conditions of the insurance, and naming the Town as additional named insured,
all of which shall be subject to the approval of the Town Solicitor.
(2) The policy shall comply with the following provisions:
(a) the minimum limit per occurrence shall be $5,000,000 all inclusive for property damage and
personal liability;
(b) it shall not contain a clause for exclusion for blasting; and
(c) it may not be cancelled unless prior notice by registered letter has been given to the Town by
the insurer thirty days in advance of the expiry date.
(3) The policy premium must be paid initially for a period of one year and the policy shall be renewed
for further one year periods until the Final Acceptance Certificate has been issued by the Town's
Director of Public Works.
(4) If the policy coverage is subject to a deductible amount, the Owner shall file with the Town, when
filing the Certificate of Insurance, a certified cheque or letter of credit with the Town in the
deductible amount, as a deposit, together with a letter from the Owner authorizing the Town to
appoint an independent adjuster and to investigate claims less than the deductible amount and
authorizing the Town to pay such claims deemed valid by the adjuster out of the deposit; the Owner
shall be responsible for all adjustment service costs and shall maintain the deposit throughout the
term of this agreement in the amount of the deductible.
(5) The provision of the insurance policy required by this section shall not relieve the Owner from
liability for claims not covered by the policy or which exceed its limits, if any, for which the Owner
may be held responsible.
PART 3 - DEVELOPING THE PROJECT
25. CONSTRUCTION AND OCCUPANCY OF BUILDINGS
(I) No building permit shall be issued for any building or part of a building on the Lands until sewer and
water facilities are available, and in the opinion of the Town's Director of Public Works, capable of
providing adequate service.
(2) No building or pan of a building on the Lands shall be occupied except upon the issuance of a
municipal occupancy permit.
(3) No application for a municipal occupancy permit for a building or pan of a building shall be made
except upon the following conditions:
(a) slorm sexier, sanitary scx~er and x~atcr facilities are installed and in operation to adcquatcl.x
~cr'xc such building or part thereof:
(b) e}ectric scrx}ce is complcled and in opcrati<m: and
10
(c) such curbs, as in the opinion of the Town's Director of Public Works, are required to be
completed prior to occupancy have been constructed on the road immediately in front of the
building or part thereof and extended to an existing maintained public road.
26. DESIGN PLANNING - BUILDINGS AND NOISE ATTENUATION STRUCTURES
(1) Prior to the issuance of any building permit for the construction of any building on the Lands and the
construction of any noise attenuation structure in or adjacent to the project, the Owner shall submit
to the Town's Director of Planning, for approval, a report outlining siting and architectural design
objectives for the project.
(2) That report may be required, at the Director's option, to provide the following information:
(a) building massing;
(b) streetscape;
(c) exterior materials and colours;
(d) architectural style;
(e) visual variety;
(f) energy conservation measures; and
(g) any other data or information reasonably required.
(3) Prior to the issuance of each building permit for the construction of a building on the Lands, the
Owner shall submit to the Town's Director of Planning, for approval, site plans and architectural
drawings for that building.
(4) Those plans and drawings may be required, at the Director's option, to provide the following
information:
(a) the location &all buildings and structures to be erected and the location of all facilities and
works associated therewith;
(b) the location of landscaping features, including trees to be preserved;
(c) streetscape for front, rear and flankage elevations at a scale acceptable to the Director;
(d) streetscape to show all street furniture and vegetation;
(e) the relationship of buildings by blocks; and
(f) any other data or information reasonably required.
27. SPECIFIC PROVISIONS RESPECTING DEVELOPMENT
The Owner shall comply with any specific provisions respecting the development of this project set out in
Schedule C.
PART 4 - FINANCIAL MATTERS
28. EXPIRY OF SECURITIES
(I) Should any letter of credit security required to be provided hereunder expire before the Town
releases the Owner from the terms and conditions hereof, the Owner shall provide to the Town at
least 30 days in advance of the expiry date of that security, a further security to take effect upon the
expiry.
(2) Such further security shall be in a form and amounl safisfactor3 to the Toxin.
(3) Should ilo stlull l't~l'llacr ',ccuritx be proxided as rcqtiircd, then thc loxsn shall haxc ttqc right
con,,cn thc expiring securit.,, into cash and hold the cash in lieu of and for the same purposes as
expiring sccuril.x.
11
29. P.z~.YMENT OF LIENS AND OTHER CLAIMS
(1) The Owner shall discharge or vacate any liens or claims filed with the Town or registered on title to
any Town-owned lands within thirty days of being requested to do so by the Town.
(2) At the end of the maintenance period, as extended during any rectification period, the Owner shall
file with the Town a Statutory Declaration stating that,
(a) all materials have been supplied and all services and works have been completed in the
project with respect to the construction and installation of Works and other services;
(b) all accounts for work or service performed and materials placed or furnished upon or in
respect of the construction and installation of Works and other services in the project have
been fully paid and satisfied and no person is entitled to claim a lien under the Construction
Lien Act against the Town or any Town-owned land;
(c) there are no judgments or executions filed against the Owner;
(d) nothing is owed by the Owner or claimed against it for unemployment insurance deductions,
income tax deductions, or by way of contribution or assessment under the Wor~rs'
Compensation Act;
(e) the Owner has not made any assignment for the benefit of creditors, nor has any receiving
order been made against it under the Bankruptcy Act, nor has any petition for such an order
been served upon the Owner; and
(f) 45 days have passed since the completion of the construction, installation, and last
rectification of the Works and services.
30. PAYMENT OF INTEREST ON OVERDUE AMOUNTS PAYABLE
The Owner shall pay interest at the rate of 18 per cent per year to the Town on all sums of money payable
hereunder which are not paid on the due dates calculated from such due dates.
31. P~,YMENT OF REALT~Y_AND BUSINESS TAXES / LOCAL IMPROVEMENT CHARGES
(I) The Owner shall pay in full as they come due all realty and business taxes assessed against the Lands
or against the Owner as required by law from time to time.
(2) Before this Agreement will be executed by the Town, the Owner shall commute and pay to the Town
or to the Regional Municipality of Durham all local improvement charges assessed against the
Lands.
32. PAYMENT~_F ENGINEERING. LEGAL AND REGISTRATION FEES
(I) Before this Agreement will be executed by the Town, the Owner shall pay by certified cheque to the
Town an Engineering Drawing Inspection Fee in the amount set out in Schedule C for the
examination and inspection done by the Town's Public Works Department in the processing of the
engineering drawings for this project.
(2) Before this Agreement will be executed by the Toxin. the Oxxner shall pay by certified cheque to the
Toxin a Dexelopment Agreement Processing Fee in the amount set out in Schedule C for
preparation and processing of this Agreement b.x the Tov, n's Icgal Serxices Dcpartmcm.
(3) The Ou. ner shall pa), all registration costs incurred by the Town relating in any v, a3 to lhe
registration of this Agreement. or any other doctnncnlali~m rdating to thiq pr,~icct, i~ch~ding
12
PART $ - TRANSFERS AND REGISTRATIONS
33. TRANSFERS OF LANDS OR INTERESTS IN LANDS
(1) Upon executing this Agreement, the Owner shall convey or cause to be conveyed to the Town, free
and clear of all encumbrances and at no cost to the Town, all of the lands or interests in lands
identified in Schedule A for the purposes set out therein.
(2) The Owner hereby warrants that, upon such conveyance, neither the title to the lands conveyed nor
their physical state and condition shall prevent the Town from lawfully or physically using the lands
for the purposes for which they are being conveyed as set out in Schedule A.
(3) Any Transfer/Deed given pursuant to this Agreement shall be in a form acceptable to the Town
Solicitor and any Transfer/Deed of a storm drainage works easement shall contain the Storm
Drainage Works Easement Schedule set out in Schedule A.
(4) The Town may complete or alter any description of land in this Agreement or in any Transfer/Deed
given pursuant to this Agreement so as to make the description correspond with the proper
description of the land.
34. REGISTRATION OF AGREEMENT
(I) This Agreement shall be registered by the Town in the Land Registry Office for the Land Titles
Division of Durham (No. 40).
(2) The Owner shall give to every purchaser of the Lands or any part of the Lands actual notice of the
existence and the terms of this Agreement and shall include an acknowledgement in any offer to
purchase or other similar document dealing with the Lands, or any part of them.
(3) The Owner shall indemnify and save harmless the Town from any loss, inconvenience or damage
which may result to the Town from the Owner's failure to comply with subsection (2) and against
any action or claim made against the Town by any person other than the Owner arising out of the
execution by the Town of this Agreement.
(4) The Owner shall execute such further assurances of the rights hereby granted as ma~, be deemed
necessary by the Town.
IN W1TNESS WHEREOF the individuals comprising Owner have hereunto affixed their hands and seals, certifying
as they do so that they are each at least eighteen years of age and that they are spouses of one another, and the Town
has hereunto affixed its Corporate Seal attested by the hands of its authorized officers.
SIGNED, SEALED AND DELIVERED
In the presence of
Nick Hatziantoniou Seal
Susan Hatziantoniou Seal
THE CORPORATION OF TIlE l'O~k~ OF P1CKERING
Wayne Anhurs, Mayor
Bruce Taylor, (lerk
13
ENCUMBRANCER - CIBC MORTGAGE CORPORATION
The Encumbrancer hereby postpones any rights or interests which it has in the Lands with the intent that this
Agreement shall take effect as though executed and registered prior to the creation of any such right or interest and
prior to the execution and registration of any mortgage, agreement or other document creating or defining any such
right or interest;
And the Encumbrancer hereby covenants and agrees with the Town that this Agreement and any conveyance,
easement or other document given pursuant to this Agreement, shall have priority over the rights of the
Encumbrancer in the Lands with the intent that the Encumbrancer or anyone claiming under it shall at no time
exercise in relation to the Lands any right, title or claim which could not be exercised by the Owner by reason of the
terms of this Agreement.
Dated at Toronto, Ontario, this day of ,1995.
SIGNED, SEALED AND DELIVERED
CIBC MORTGAGE CORPORATION
We have authority to bind the Corporation.
14
TRANSFERS OF LANDS OR INTERESTS IN LANDS OR CREDITS IN LIEU THEREOF
(Section 33)
I. CONVEYANCES REQUIRED TO BE MADE TO THE TOWN
~ purpose Interest to be Conveyed
Part l, Plan 40R-XXXXX Road widening Fee simple
Any portion of the Lands Storm drainage works Easement
determined by the Town's
Director of Public Works
Any other lands outside the Storm drainage works Easement
Lands determined by the Town's
Director of Public Works
2. PROVISION OF PARKLAND
The Owner shall pay to the Town prior to the registration of this Agreement the sum of $8,835 instead of a
parkland conveyance.
3. STORM DRAINAGE WORKS EASEMENT REFERENCE PLANS
(I) The Owner shall obtain and deliver to the Town one draft copy of each proposed reference plan
required to effect the conveyance of any easement or easements required under section 1 of this
Schedule within 30 days ofthe Town's request to do so, and the provisions of subsections (2) and (3)
will apply.
(2) Upon the completion of the construction and installation of the storm drainage works within each
easement shown on any proposed reference plan, the Owner's Consulting Engineer shall advise the
Town's Director of Public Works of the actual location of the works in relation to the proposed
easement or easements, and if the Director is satisfied with the actual location of the works, the
Owner shall register that reference plan and provide four copies of the plan as registered to the To~
Solicitor.
(3) If the Town's Director of Public Works is not satisfied with the actual location of the works in
relation to the proposed easement or easements, the Owner shall obtain and deliver to the Town one
draft copy of a revised proposed reference plan, and the provisions of subsection (2) and of this
subsection will continue to apply.
4. ;~TORM DRAINAGE WORKS EASEMENT SCHEDULE
Where a conveyance of an easement is for storm drainage works purposes, the following Schedule shall be
attached to the Transfer/Deed of Easement:
(7) INTEREST/ESTATE TRANSFERRED
Subject to the follox~ing terms and condilions, lhe free. uninterrupled and unobstructed right and easement to
la), col'~strucl, operate, maintain, inspect, alter, repair, replace, reconstruct and remo',e storm drainage x~orks
together v, ith appurtcmmccs thereto (herein called the "v,'orks"). in, o,.er, along, across, upon and under the
land dc~,cribcd in Bvx 5 {l~crcin called ~.h~: "{ands"}, and to drail~ storm v, atc~ ill, o~,~:r, along, acre-,-,.
and under the lands, together v. ith thc right to the Transferee, its servants, agents and contractors x~ith all
nccessar.,, xchicles, supplies and equipment to er~ler onto lhe lands and pass and rcpa~,s o,.er the lands for
15
The terms and conditions which the parties hereto covenant and agree to observe and be bound by are as
follows:
I. The Transferee shall, except in case of emergency, before commencing any work authorized hereby,
give to the Transferor forty-eight hours previous written notice thereof, and in cases of emergency
such previous notice thereof as is reasonably possible.
2. Upon completion of any work, the Transferee shall fill in all excavations, restore fences, and restore
the surface of the ground by restoring all topsoil and grass cover disturbed thereby, and do necessary
grading to ensure soil and slope stability, and remove all equipment.
3. The Transferor shall not erect any building or structure (except a fence) on the lands, and shall not
place or remove any fill on or from any part of the lands without the previous written consent of the
Transferee.
4. The right and easement granted herein shall be subject to all leases, licences, and any rights of use or
occupation existing at the date hereof, and the Transferor may from time to time renew or extend
these or make new ones, so long as they do not interfere unreasonably with the right and easement
herein granted.
5. The Transferor hereby releases the Transferee from any claim which may arise out of the exercise by
the Transferee of the right and easement granted hereby or which may arise out of the existence of
the storm water or the existence, operation or non-operation of the storm drainage works provided
the Transferee has complied with all of the terms and conditions herein.
6. The Transferor shall execute such further assurances of the right and easement granted hereby as the
Transferee may reasonably request in writing.
7. The burden of this Transfer and of all the terms and conditions contained herein shall run with the
lands.
8. This Transfer and all ofthe terms and conditions contained herein shall enure to the benefit of and be
binding upon the Transferor and the Transferee and their respective heirs, executors, administrators,
successors and assigns.
LAND BENEFITTED (DOMINANT TENEMENT)
9. The benefit of this Transfer and all of the terms and conditions contained herein shall run with all
other lands and interests in lands owned, occupied or used by the Transferee for the purpose of
operating and maintaining storm drainage works.
16
REQUIRED FORM FOR PERFORMANCE AND MAINTENANCE SECURITY LETTER OF CREDIT
(Section 2 I)
To: The Corporation of the Town of Pickering
Pickering Civic Centre
One The Esplanade
Pickering, Ontario
LIV 6K7
We hereby authorize you to draw on [name of bank], ]address of bank[, for account of ]name of company or
companies obtaining security[ up to an aggregate amount of [amount of security in figures and in full[ available
by drafts at sight for 100% of demand as follows:
Pursuant to the request of our customers(s), the said ]name of company or companies obtaining securityl, we
[name of bank], ]address of bank], hereby establish and give to you an irrevocable Letter of Credit in your favour
in the total amount of [amount of security in numbers and in wordsl which may be drawn on by you at any time
and from time to time upon written demand for payment made upon us by you which demand we shall honour
without enquiring whether you have a right as between yourself and our said customer(s or any of them) to make
such demand, and without recognizing any claim of our said customer(s or any of them).
Provided, however, that you are to deliver to [name of bank], laddress of bank], at such time as a written demand
for payment is made upon us a certificate signed by you agreeing or confirming that monies drawn pursuant to this
Letter of Credit are payable to you or are to be or have been expended pursuant to obligations incurred or to be
incurred by you with reference to your file regarding a Development Agreement dated [date of Agreementl,
between [name of signatories to Agreement, other than Town and Encumbrancer(s)] and The Corporation of
the Town of Picketing; this Letter of Credit is given as the Performance and Maintenance Security required by
section 21 of that Agreement.
Partial drawings are permitted.
The amount of this Letter of Credit shall be reduced from time to time as advised by notice in writing given to us
from time to time by you.
This Letter of Credit will continue up to and including [date of expiry of Letter of Creditl and will expire on that
date and you may call for payment of the full amount outstanding under this Letter of Credit at any time up to the
close of business on that date. It is a condition of this Letter of Credit that it shall be deemed to be automatically
extended for one year from the present or any future expiration date hereof, unless thirty days prior to any such date,
we shall notify you in writing by registered mail that we elect not to consider this Letter of Credit renewed for any
such additional period.
We hereby covenant with drawers, endorsers, and bona fide holders of drafts drawn under and in accordance with
the terms of this credit that such drafts will be duly honoured if drawn and negotiated on or before [date of expiry
of Letter of Credit].
The drafts drawn under this credit are to be endorsed hereon and shall state on their face that they are drawn under
]name of bank], [address of bank].
DATED this day of ,19
Instructions for completing Lener of Credit:
I. Letter of Credi~t must be t.,,ped on bank letterhead
2. Information required in square brackets must be provided where indicated, without brackels.
3. Phrases shown in round brackels musl be inch~ded :~.ilhotll brackets ,.'.here there are txxo or more companies
comprising the customer.
4. Thc date in Ibc sixth l, ara?apb nlu<l be ;il Icn',l one .'.ear from t)le dille of Ihe l crier of ('rcdit.
5. Tl/c dilt¢ in lbo sex. elliS paragraph Illll~,l be tile Nilmo as tile date ill tbe sixth paragraph.
6. Bank signalories mtist sbov,' name. printed or 13ped, and lille, in addition to signalure.
17
ENGINEERING AND LEGAL FEES
(Section 32)
SPECIFIC PROVISIONS RESPECTING DEVELOPMENT
(Section 27)
1. ENGINEERING DRAWING INSPECTION FEE PAYABLE
The amount of the Engineering Drawing Inspection Fee payable for this project is $210.
2. DEVELOPMENT AGREEMENT PROCESSING FEE PAYABLE
The amount of the Development Agreement Processing Fee payable for this Agreement is $1,605 [$1,500
plus $105 GST.]
3. EXPECTED NUMBER OF DWELLINGS
(I) This Agreement has been entered into in the expectation that six dwellings are to be constructed on
the Lands, one each on Parts 4, 5, 6, 7, 8 and 9, Plan 40R-XXXXX.
(2) If more or less than six dwellings are to be constructed in this project, the Town at its sole discretion
may require the Owner to obtain new approvals and authorizations under this Agreement and may
prohibit any development until the new approvals and authorizations are obtained.
4. CONTRIBUT!QNS TO SHARED SERVICE COSTS
Before this Agreement will be executed by the Town, the Owner shall provide to the Town,
(a) a certified cheque payable to "Altona West Developments" in the amoun,t of $2,917.00, being,
(i) $1,355.00 as the portion of the costs to that company of the acquisition of the Petticoat Creek
detention pond and access easement, which benefits the lands in this project, and
(ii) $1,562.00 as the portion of the costs to that company of the oversizing of stormwater
management facilities in Plan 40M-1507 and 40M-1508, Picketing, which also benefits the
lands in this project;
and
(b) a certified cheque payable to "Nugget Construction Co. Ltd." in the amount of $50,778.71, being the
portion of the costs to that company of the servicing of 91.57 metres of frontage on Oakburn Street
(west side) adjacent to the lands in this project, which also benefits the lands in this project.
18
o, Transfer/Deed of Land
Form 1 -- Land Reglatmtlon Reform Act, 1984
(1) Registry [] Land Titles [] ']~2) Page I of pages
(3) Property Block Property
Identifier(s) Additional:
se.
(4) Consideration
Dollars $
(5) Description This is a: Property Property
Division [] Consolidation []
New Property Identifiers
Additional:
Executions
Additional:
See
Schedule
(6) ThiScontains (a) Plan/SketchRSdescripti°n~-~ (b) Schedule for: (7) Intamat/Estate Tranaferred
Document New Easement : Additional Fee Simple
Description [~ Parties [] Other []
(8) Transferor(s) The transferor hereby transfers the land to the transferee and certifies that the transferor is at least eighteen years old and that
Date of Signature
............................................................................... Y M D
Name(s) Signature(s)
>(9) Spouse(s) of Transferor(s) I hereby consent to this transaction Date of Signature
Name(s) Signature(s) Y M D
(10) Transferor(s) Address
for Service
~>(11) Transferee(s) Date of Birth
Y M D
TOWN OF PICKEP. ING Wayne Arthurs, Mayor
Bruce Taylor, Clerk
(12) Transferee(s) Address
; forService Pickering civic ~lex, One The Esplanade, Pickering, Ontario L1V 6K7
~ I(15) Tra/lafero~a) The transferor verifies that fo the best of the transferor's knowledge and belief, this transfer does not contravene section 49 of the
Planning Act, 1983, Date of Signature Date of Signature
J Solicitor for TransferoHs) I have explained the effect of section 49 of the Planning Act, 1983 to the transferor and I have made inquiries of the transferor
.~ to determine that this transfer does not contravene that section and based on the information supplied by the transferor, to the best of my knowledge
z J and belief, this transfer does not contravene that section I am an Ontario solicitor in good standing. Date of Signature
,---0Name and [ Y ,, M ; D
~. Address of .
O Solicitor S~gnature ........................... : ...... : ........
~ ~ I (14) Solicitor for Transferee(a) I have investigated the title to this land and to abutting land where relevant and I am satiafied that the title records
< ~ ~ reveal no contravention as set out in subciause 49 (21a) (c) (ii) of the Planning Act, lCj~$ and that to the best of my knowledge and belief this
~1 -~ ~ I transfer does not contravene section 49 of the Planning Act 1983 I act independently of the solicitor for the transferor(s) and I am an Ontario
~. J-~; c~l Name and Date of Signature
(15) Assessment Roll Number i cb/. M~n i Map Sub Par. ~ Fees and Tax
et prop*rty i '[
>(16) Municipal Address of Property : i (17)' Document Prepared by: Registration Fee
C.M. Timothy Sheffield I~11LandTransferTax
Town Solicitor
Town of Pickering I!/
One The Esplanade
~. ~,. Pickering, Ontario L1V 6K7 ,,~u,G,~] Tota~
10173 (12/84)
(7) INTEREST/ESTATE TRANSFERRED
Subject to thc following terms and conditions, the free, uninterrupted and unobstructed fight
and easement to lay, construct, operate, maintain, inspect, alter, repair, replace, recon.struct and
remove storm drainage works together with appmncnanccs thereto (herein called the "works"),
in, over, along, across, upon and under the landdescribed in Box 5 (herein called the "lands'),
and to drain storm water in, over, along, across, upon and under the lands, together with the
right to the Transferee, its servants, agents and contractors with all necessary vehicles, supplies
and equipment to enter onto thc lands and pass and repass over the lands for thc pttrpose of
exercising or enjoying any of thc rights granted herein.
The terms and conditions which thc parties hereto covenant and agree to obscrve and be bound
by arc as follows:
1. The Transferee shall, except in case of emergency, befog commencing any work
authorized hereby, give to thc Transferor forty-eight hours prcvious writlcn notice
thereof, and in cases of emergency such prcvions notice thereof as is reasonably possible.
2. Upon completion of any work, the Transferee shall fill in all excavations, restore fences,
and restore the surface of the ground by restoring all topsoil and grass cover disturbed
thereby, and do necessary grading to ensure soil and slope stability, and remove all
equipment.
3. The Transferor shall not erect any building or structure (except a fence) on thc lands, and
shall not place or remove any fill on or from any part of the lands without thc previous
written consent of thc Transfe[ee.
4. The right and easement granted herein shall be subject to all leases, licences, and any
rights of usc or occupation existing at the date hereof, and tbe Transferor may from th,ac
to time renew or extend these or make new ones, so long as they do not interfere
unreasonably with the right and easement herein granted.
5. Thc Transferor hereby releases thc Transferee from any claim which may arise out of the
exercise by the Transferee of thc right and casement granted hereby or which may arise
out of the existence of the storm water or the existence, operation or non-operation of the
storm drainage works provided the Transferee has complied with all of the terms and
conditions herein.
6. The Transferor shall execute such further assurances of the right and easement granted
hereby as the Transferee may reasonably request in writing.
7. The burden of this Transfer and of all the terms and conditions contained herein shall nm
with the lands.
8. This Transfer and all of the terms and conditions contained herein shall enure to the
benefit of and be binding upon the Transferor and the Transferee and their respective
heirs, executors, achnhzistrators, successors and assigns.
LAND BENEPTI*TED (DOMINANT TENEMENT)
9. The benefit of this Transfer and all of the terms and conditions contained herein shall nm
with all other lands and interests in lands owned, occupied or usod by the Transferee for
the purpose of operating and maintaining storm drainage works.
OTHI3