HomeMy WebLinkAboutBy-law 4232/93 THE CORPORATION OF THE TOWN OF PICKERING
BY-LAW NO, 4232/93
Being a by-law to authorize the execution of a
Subdivision Agreement and related documentation
respecting the development of Part Lot 6, Plan 282,
Pickering (668390 Ontario Ltd./Lee; 18T-85006).
WHEREAS the proposal to subdivide and register a plan of subdivision of part of Lot 6, Plan 282,
Picketing, has been recommended for approval by the Council of The Corporation of the Town of
Pickering and approved by the Commissioner of Planning for the Regional Municipality of Durham as
Draft Plan 18T-85006, subject to several conditions, one of which requires the entering into of a
satisfactory Subdivision Agreement with The Corporation of the Town of Picketing, pursuant to the
provisions of the Planning Act, R.S.O. 1990, chapter P. 13, section 51(6); and
WHEREAS, pursuant to the provisions of the Municipal Act, R.S.O. 1990, chapter M.45, section
191(1), the Council of The Corporation of the Town of Pickering may pass by-laws for acquiring any
land or interest therein for the purposes of the corporation;
NOW THEREFORE the Council of The Corporation of the Town of Pickering HEREBY ENACTS AS
FOLLOWS:
1. The Mayor and Clerk are hereby authorized to execute a Subdivision Agreement, in the form
attached hereto as Schedule A, between 668390 Ontario Ltd., Robert Lee and loyce Lee and
The Corporation of the Town of Pickering, respecting the development of part of Lot 6, Plan
282, Picketing, being Draft Plan 18T-85006.
2. The Corporation of the Town of Picketing shall acquire those lands or interests in lands
referred to in section 33 and identified in Schedule A of that Subdivision Agreement subject to
the terms and conditions and for the purposes set out therein.
3. The Mayor and Clerk are hereby authorized to execute Transfers/Deeds of Easement, in the
form attached hereto as Schedule B, effecting the acquisition by The Corporation of the Town
of Picketing of any interests in land in the nature of storm drainage works easements.
BY-LAW read a first, second and third time and finally passed this 7th day of June, 1993.
Wayne Xrt~rs, May~r
Bmce Taylor, Clerk
o.,.,,o °'"'°V'"c' Transfer/Deed of Land A
Fern -- Lend Registration Refoem Ac~ 1~
(1) R~bt~ ~ L~d Tm. T(2) Page 1 of ~ges
(3) P~ Bilk Pro~
I~tlfle~l) A~it~:
(4) Con~ld~atWn
D~la~ $
(5) De~dptlon ~is la a: Pro~ Pro~y
Division ~ Con~lid~tion ~
New Properly Identifiem
Additional:
See
(6) This (a) Redescription :(b) Schedule for: (7) Interest/Estate Trarmfen'ed
: Description [] Parties [] Other []
Contains Plan/Sketch []
Name(s) Signature(s)
Name(s) Signature(s) y M D
(10) Transfm'or(s) Address
for Service
THE CORPORATICN OF THE
· . . .~....0~'.. P.I..~....~. ............................ .~.a .~.. A_---P_ht~s, . .Ma...!~q.r' ........... i :.
Bruce Taylor, Clerk
(12) Transferee(s) Address
forService Pickering Civic Centre, One The Esplanade, Pickering, Ontario L1V 6K7
Signature.
Name and I Y ~ M i D
~Signature. ' . ' ~.
Solicitor
l solicitor in good standing, o · r- .
~)-~1~., AddressName andof D~te of S~natur~
~,~'~ I Solicitor
I
16) Municipal Address of Property (17) Document Prepared by:.
One The Esplanade
Pickering, Ontario ,;)'1 Total
THIS SUBDMSION AGREEMENT made June 17, 1993, pursuant to the provisions of section 51 of
the Planning Act, R.S.O. 1990, chapter P.13,
BETWEEN:
668390 ONTARIO LTD.,
and
ROBERT LEE and JOYCE LEE,
herein collectively called the "Owner",
OF THE FIRST PART,
THE CORPORATION OF THE TOWN OF PICKERING
herein called the "Town"
OF THE SECOND PART.
WHEREAS the Owner proposes to subdivide pa~ of Lot 6, Plan 282, in the Town of Picketing, in the
Regional Municipality of Durham, and to register a plan of subdivision of those lands, as shown on a
draft plan of subdivision designated as Draft Plan Number 18T-85006, and is required as a condition of
approval thereof to enter into a subdivision agreement with the Town pursuant to section 51 of the
Planning Act, R.S.O. 1990, chapter P.13;
NOW THEREFORE, THIS AGREEMENT WITNESSETH THAT, in consideration of the Town
consenting to the registration of the proposed plan of subdivision, and the covenants hereinafxer
expressed, the Parties hereto covenant and agree one with the other as follows:
PART 1 - INTERPR~:I11gG AND APPLYING THIS AGI~F..F..MENT
The lands affected by this Agreement (the "Lands") are Lots I to 38, both inclusive, and Blocks
39, 40 and 41, Plan 40M- , Pickering.
2. STATUS OF THIS AGREEMENT
(1) In the event the plan of subdivision is not registered on or before February 17, 1994, this
Agreement shall be null and void and of no further effect, and the Town shall not be
liable for any expenses, costs or damages suffered by the Owner as a result thereof.
(2) This Agreement is entered into and executed by the Owner for the purpose of having the
Town act in reliance on the covenants by the Owner contained herein and the Owner
hereby waives any right or claim which it now has or may hereinafter acquire which is
inconsistent with the terms of this Agreement.
3. E P ~
(1) Whenever in this Agreement the pronoun "it" is used, it shall be read and construed as
"he", "she", "they", "him", "her" or "them", and the number of the verb agreeing
therewith shall be construed accordingly.
(2) Schedules A, B, C, D and E attached hereto shall form part of this Agreement.
(3) Time shall be of the essence of this Agreement.
This Agreement shall be enforceable by and against thc Parties hereto, theft heirs, cxccutor~,
administrators, successors and assigns, and the Agreement and all the covenants by the Owner
contained herein shall run with the Lands for the benefit of the Town and the land or interests in
land owned by the Town upon the registration of the plan.
(1) Any notice required to be given hereunder may be given by personal delivery or
registered mail,
(a) in the case of the Owner, to
William $. Daniell, President
668390 Ontario Ltd.
1029 McNicoll Avenue
Scarborough, Ontario
MIW 3W6
and
(b) in the case of the Town, to
The Town Clerk
The Corporation of the Town of Picketing
Picketing Civic Complex
One The Esplanade
Pickering, Ontario
L1V 6K7
(2) Each Party may redesignate the person or the address, or both, to whom or to which
such notice may be given by giving written notice to the other.
(3) Any notice given in accordance with this section shall be deemed to have been given on
the second day following the day of delivery or the day of mailing, as the case may be.
The Owner shall retain a licence from any subsequent purchaser of the Lands, or any part
thereof, to enable the Owner and the Town's inspectors to enter upon the Lands in order to
comply with the provisions of this Agreement.
7. OWNER'S GENERAL UNDERTAKING
The Owner shall complete in a good workmanlike manner for the Town, all the municipal
services as hereinafter set forth to the satisfaction of the Town, and shall complete, perform or
make payment for such other matters as may be provided for herein.
Every provision of this Agreement by which the Owner is obligated in any way shall be deemed
to include the words "at the expense of the Owner and at no expense to the Town" unless the
context requires otherwise.
PART 2 - CONSTRUCTING THE TOWN'S SERVICES
9. CONSULTING ENGI2qEERS
(1) The Owner shall retain a Professional Engineer as the Consulting Engineer of the
Owner to cany out all the necessary engineering and to supervise the work required to
be done for the development and construction of the project.
(2) Such Consulting Engineer, or any successor thereto, shall continue to be retained until
the work required to be done for the development and construction of the project is
completed and formally accepted by the Town.
-2-
(3) The Owner may change from one Consulting Engineer to another at any time or times
during the development and construction of the project, so long as the Owner has a
Consulting Engineer retained at all times.
10. CONSTRUCTION / INSTALLATION OF TOWN WORKS AND SERVICES
(1) The Owner shall obtain all required approvals and shall construct or install to Town
standards and shall provide to the Town, complete in every detail, the following Town
works and services (the "Works") as shown on plans submitted by the Owner's
Consulting Engineer to the Town and approved by the Town's Director of Public Works
in accordance with the Town's specifications for such Works:
(a) Town roads within the plan, complete with all signs and other appurtenances;
(b) Town roads adjacent to the plan and not separated from the plan by a reserve or
reserves, complete with all appurtenances;
(c) removal and replacement of any temporary turning circle located immediately
adjacent to the plan on a Town road to be extended into the plan;
(d) street storm sewers on roads referred to in (a) and (b), complete with curbs,
gutters, catchbasins and manholes;
(e) storm water drainage and management system serving the lands in the plan and
lands outside the plan but draining through the plan, complete with detention or
retention facilities, quality control devices and outlets;
(f) boulevards and sidewalks on Town roads within the plan, on Town roads
adjacent to the plan but not separated from the plan by a reserve or reserves,
and on Town roads to be extended into the plan where the Owner is required to
remove and replace a temporary turning circle;
(g) street lighting on Town roads within the plan, on Town roads adjacent to the
plan but not separated from the plan by a reserve or reserves, and on Town
roads to be extended into the plan where the Owner is required to remove and
replace a temporary taming circle;
(h) street tree planting on Town roads within the plan, on Town roads adjacent to
the plan but not separated from the plan by a reserve or reserves, and on Town
roads to be extended into the plan where the Owner is required to remove and
replace a temporary tuming circle;
(i) walkways on walkway blocks and park entrances, complete with walkway
fencing and lighting; and
other fencing, including,
(i) fencing adjacent to commercial sites, school sites, parks, open space,
storm water management facilities and roads adjacent to the plan and
separated from the plan by a reserve or reserves, and
(ii) noise attenuation fencing.
(2) If at any time prior to the acceptance of the Works, the Town's Director of Public
Works is of the opinion that additional works are necessary to provide adequately any
of the public services required by the project, the Owner shall construct, install or
perform such additional works at the request of the Director.
(3) All Works shall be constructed and installed in accordance with the Town's
specifications and in a good and workmanlike manner under the supervision of the
Owner's Consulting Engineer and under the observation of the Town's inspectors or, in
~tbe case of street lighting, Picketing Hydro's inspectors.
(4) The Owner shall conduct video inspections of all underground services required to be
constructed or installed hereby and shall provide a VI-IS-format videotape record of
those inspections to the Town.
(5) The Owner shall pay to the Town the Town's costs of inspection, including but not
necessarily limited to, salaries and wages of inspectors, testing fees and administration
fees, within 30 days of invoices being rendered.
-3-
1 I. GENERAL REGULATIONS RESPECTING SERVICING
(1) The construction of Town roads shall include the construction of paved driveway
approaches between the curb and sidewalk or, where no sidewalk is to be provided,
between the curb and the lot line.
(2) Where the construction or installation of services involves a continuation or extension
of existing services, the Owner shall join into the existing services, including
adjustment of grades where necessary, in a good and workmanlike manner.
(3) The Owner shall not dump nor permit to be dumped any fill or debris on, nor remove or
permit to be removed any fill from, any public lands, other than in the actual
construction of roads in the project without the written consent of the authority
responsible for such lands.
(4) The Owner shall not burn nor permit to be burned any refuse or debris within the project
or adjacent to it.
(5) The Town's Director. of Public Works may have qualitative or cKuantitative tests made
of any materials which have been or axe proposed to be used m the construction or
installation of any services required by this Agreement, and the cost of such tests shall
be paid by the Owner within 30 days of invoices being rendered.
(6) The Owner shall pay, within 30 days of invoices being rendered, the costs of,
(a) relocating any existing services or utilities required to be relocated by the
construction or installation of Works, services, or utilities in the project, and
(b) moving any Works, services or utilities installed in driveways or so close
thereto, in the opinion of the Town's Director of Public Works, as to interfere
with the use of the driveway.
(7) Unless otherwise provided herein, the Owner shall perform any work required to be
done under this Agreement to the specifications of the Town in effect at the date hereof.
(8) The Owner shall provide and erect temporary signs of such nature and at such locations
as designated by the Town's Director of Public Works.
12. ELECTRICAL SERVICES
Where electricity, cable televisiofi service or telephone service is to be provided to any lot or
block in the project, it shall be provided underground and in accordance with the standards and
specifications of Picketing Hydro-Electric Commission, Trillium Cable T.V. Limited or Bell
Canada, as the case may be.
13. TREE INVENTORY / TREE PRESERVATION PROGRAM
(1) The Owner shall submit a Tree Inventory and a Tree Preservation Program prepaxed by
a qualified expea, and based upon the Town-approved Grading Control Plan, indicating
which existing trees in the project may be preserved to the Town's Director of Public
Works for the review and approval of the Town's Director of Planning and Director of
Community Services and Facilities, and shall implement the Program as approved only.
(2) Until the Tree Preservation Program is approved the Owner shall not commence, nor
allow to be commenced, any aspect of the development of the lands in the project,
including ~he removal of any tree.
(3) In the event that any tree required to be preserved by the approved Tree Preservation
Program is removed or is, in the opinion of the Town's Director of Community Services
and Facilities, damaged to such an extent that its value or longevity is decreased or is
likely to be decreased, then the Owner shall replace that tree with a tree of a height,
diameter and species determined by the Director; such replacement shall be at no cost to
the Town.
(4) The Owner's liability under subsection (3) shall continue until,
(a) where the lands upon which the tree is located comprise a residential building
lot or block, twelve months after the completion of the sodding on the lot or
block, or
-4-
(b) where the lands upon which the tree is located comprise lands other than a
residential building lot, the issuance by the Town of the Final Accel~ance
Certificate.
14. GRADING CONTROL PLAN / LOT DRAINAGE AND SODDING
(l) The Owner shall submit to the Town, for the _approval of the Town's Director of Public
Works, a Grading Control Plan prepared by the Owner's Consulting Engineer,
establishing the proposed grading of the lands in the project to provide for the proper
drainage thereof-and the drainage of all adjacent lands which drain through the lands in
the project.
(2) The Grading Control Plan shall be prepared in accordance with the Town's Lot
Drainage Specifications and shall not provide for the drainage of surface mn-off water
onto Town-owned parkland, open space or walkways unless provision is made for the
installation by the Owner, at no cost to the Town, of suitable swales and catch basins to
manage adequately, in the opinion of the Town's Director of Community Services and
Facilities, that surface mn-off water.
(3) The Owner shall grade all the lands in the project in accordance with the approved
Grading Control Plan, ensuring that sufficient topsoil remains as cover on all areas of
the project intended for sodding, seeding, or other planting.
(4) If the Town determines that,
(a) grading has not been done in accordance with the Grading Control Plan,
(b) grading has been done in accordance with the Grading Control Plan but
drainage problems remain, or
(c) sufficient topsoil has not been left in the appropriate areas,
the Owner shall re-grade the project, or part thereof affected, adding a sufficient amount
of topsoil if necessary, or construct catch basins, swales or other structures as may be
necessary to correct such problems, as directed by the Town's Director of Public Works.
(5) The Owner shall sod the front, side and rear yards of each of the residential lots and
blocks in the project except for paved, planted or treed areas prior to the occupancy of
the dwelling unit located thereon or within the six months immediately thereafter
except, where the occupancy of the dwelling unit occurs in November or December of
any year, the time limit fo} sodding may be extended to June 30 in the following year.
15. AUTHORIZATION TO COMMENCE WORK
The Owner shall not commence the construction or installation of any of the Works without the
written Authorization to Commence Work of the Town's Director of Public Works, which
Authorization shall not be issued until all approvals required by this Agreement have been
obtained and,
(a) four red-lined copies of this Agreement executed by the Owner and all Encumbrancers
have been provided to the Town to the satisfaction of the Town Solicitor;
(b) all monies, securities and insurance policies, as noted in this Agreement, have been
delivered to the Town to the satisfaction of the Town Treasurer and the Town Solicitor;
(c) all approvals and permits have been obtained by the Owner from the Ministry of the
Environment, the Ministry of Natural Resources and the Metropolitan Toronto and
Region Conservation Authority, or a certificate has been provided by the Owner's
Consulting Engineer that no such approvals or permits are required; and
(d) three executed copies, in a form suitable for registration, of any Tr._ansfersfDeeds
required by section 34 respecting the conveyances identified in Schedule A have been
provided to the Town in registrable form to the satisfaction of the Town Solicitor.
-5-
16. USE OF WORKS PENDING COMPLETION / EMERGENCY REPAIRS
(1) Any of the Works may be used by the Town, or by such other person or agency as may
be authorized by the Town's Director of Public Works, for the purposes for which the
Works are designed, and such use shall not be deemed an acceptance of any of the
Works by the Town, nor an assumption by the Town of any liability in connection
therewith, nor a release of the Owner from any of its obligations under this Agreement.
(2) Thc T~}wn may make emergency repairs at any time to any of the Works and may for
this purpose enter the Lands at any time; such repair or ent~ shall not be deemed an
acceptance of any of the Works by the Town, nor an assumption by the Town of any
liability in connection therewith, nor a release of the Owner from any of its obligations
under this Agreement.
17. I1WI'ERNAL / EXTERNAL ROAD MAINTENANCE AND REPAIR / SNOW PLOWING
(1) Throughout the term of this Agreement, the Owner shall,
(a) maintain all Town roads within the project in a mud and dust free condition and
free of obstructions, regardless of the source or cause of any mud, dust or
obstruction;
(b) maintain all Town roads outside the project, including boulevards, in a mud
and dust free condition and free of obstructions, where the source or cause of
the mud, dust or obstruction is an operation or operations related in any way to
the development of the project;
(c) repair all Town roads outside the project, including boulevards, where damage
has occurred as a result of an operation or operations related in any way to the
development of the project; and
(d) plow snow from and salt all Town roads within the project that are not subject
to the Town's winter control program.
(2) The Owner, within 24 hours of verbal notification by the Town to it or its
representatives, shall undertake such works as are necessary to clean, clear, repair, plow
or salt any Town road requiting such work in the opinion of the Town's Director of
Public Works or his designate.
18. COMPLETION DATES - TOWN WORKS AND SERVICES
(1) The Owner shall complete the Works in accordance with the following time limits:
(a) Town roads within the plan - two years from date of Authorization to
Commence Work;
(b) Town roads adjacent to the plan - two years from date of Authorization to
Commence Work;
(c) removal and replacement of any temporary turning circle - two years from date
of Authorization to Commence Work;
(d) street storm sewers - one year from date of Authorization to Commence Work;
(e) storm water drainage and management system (including grading and
top-soiling of non-residential lots and blocks) - one yehr from date of
Authorization to Commence Work;
(f)(i) boulevards and sidewalks on Town roads within the plan, on Town roads
adjacent to the plan but not separated from the plan by a reserve or reserves -
six months after occupang_y of first dwelling to be occupied adjacent to
segment as identified by the Town's Director of Public Works, but no later than
two years from date of Authorization to Commence Work;
(0(ii) boulevards and sidewalks on Town roads to be extended into the plan where
the Owner is required to remove and replace a temporary turning circle - two
years from date of Authorization to Commence Work;
(g) street lighting - one year from date of Authorization to Commence Work;
-6-
(h) street tree planting, two years from date of Authorization to Commence Work;
(i) walkways, walkway fencing and walkway lighting - prior to the occupancy of
any dwelling adjacent thereto;
(j)(i) other fencing adjacent to,
A parks, open space and storm water management facilities - prior to the
occupancy of any dwelling adjacent thereto;
B commercial sites and school sites one year from date of
Authorization to Commence Work; and
C roads adjacent to the plan and separated from the plan by a reserve or
reserves - six months after occupancy of fncst dwelling to be occupied
adjacent to segment as identified by the Town's Director of Public
Works, but no later than two years from date of Authorization to
Commence Work; and
(j)(il) noise attenuation fencing - prior to the occupancy of any dwelling adjacent
thereto,
following the satisfactory completion and testing of ail of which, and the approval
thereof by the Town, the Town shall issue to the Owner a Completion Acceptance
Certificate.
(2) Despite the provisions of subsections (1)(f)(i) and (1)(j)(i)C, where the occupancy of
the first dwelling unit occurs in November or December of any year, the time limit for
construction of the adjacent boulevard, sidewalk or fencing segment shah be extended
to June 30 in the following year.
19. FAILURE TO COMPLETE /IMPROPER PERFORMANCE
(1) If, in the opinion of the Town's Director of Public Works, the Owner is not constructing
or installing the Works, or causing them to be constructed or installed, within the
specified time or so that they may be completed within the specified time, or is
improperly performing the Works, or has neglected or abandoned them before
completion, or has unreasonably delayed them so that the terms and conditions of this
Agreement are being violated or executed carelessly or in bad faith, or has neglected or
refused to renew or again perform Works rejected by the Director of Public Works as
defective or unsuitable, of has in any other manner, in the opinion of the Director of
Public Works, defaulted in the performance of the terms and conditions of this
Agreement, then the Director may notify the Owner and his surety in writing of the
default or neglect and ff the notification be without effect for seven days, then the
Director shall have full authority to make any payment or do any thing, including but
not limited to obtaining materials, tools and machinery and employing persons required
for the proper completion of the Works or rectification of the default, at the cost and
expense of the Owner or his surety, or both.
(2) In cases of emergency, in the opinion of the Director of Public Works, such Director
may act without prior notice but the Owner and its surety shah be notified forthwith.
(3) The cost of rectifying the default shall be calculated by the Director of Public Works,
whose decision shall be f'mal, and may be charged to the Owner, together with a 25 per
cent engineering and administration fee, by drawing upon the letter of credit fried with
the Town under section 21.
20. GUARANTEE OF WORKS. WORKMANSHIP AND MATERIALS
(1) The Owner shah guarantee all Works, workmanship and materials employed or used in
_ the construction, installation or completion of Works, services and other requirements
under this Agreement for a minimum period of two years (the "maintenance period")
following the issuance of the Completion Acceptance Certificate by the Town.
(2) Despite any other provisions of this Agreement, the responsibilities of the Owner during
the maintenance period shall include the maintenance of the Works, including the
rectification of any unsatisfactorily installed Works.-
-7-
(3) Prior to the end of the maintenance period, the Owner's Consulting Engineer shall
submit to the Town,
(a) "as built" construction drawings for the Works complete as per Town
standards, together with that Consulting Engineer's certificate that those
drawings accurately depict the Works as constructed; and
(b) a statement by an Ontario Land Surveyor that all standard iron bats as shown
on the registered plan, and survey monuments at all block comers, at the-ends
of all curves (other than comer roundings) and at all points of change in
direction of streets in the plan have been found or re-established.
(4) Prior to the end of the maintenance period, the Town will re-inspect the Works and if,
(a) the Works are acceptable; and
(b) the Owner has performed all of its obligations under the terms of this
Agreement to the satisfaction of the Town,
the Town will issue to the Owner a Final Acceptance Certificate at which time the
Town will assume ownership of the Works and the operation and maintenance thereof,
and the maintenance period will then end.
(5) If upon the re-inspection conducted prior to the end of the maintenance period,
(a) the Works are not acceptable, or
(b) the Owner has not performed all of its obligations under the terms of this
Agreement to the satisfaction of the Town,
the Town will advise the Owner of the deficiencies, the expected rectifications, and the
time limited for implementing the rectifications (the "rectification period") and the
maintenance period shall be extended to the end of the rectification period.
(6) At the end of the rectification period, the Town will re-inspect the Works and if,
(a) the Works are acceptable; and
(b) the Owner has performed all of its obligations under the terms of this
Agreement to the satisfaction of the Town,
the Town will issue to the Owner a Final Acceptance Certificate at which time the
Town will assume ownership of the Works and the operation and maintenance thereof,
and the maintenance period will then end.
(7) If upon the re-inspection conducted at the end of the rectification period,
(a) the Works are still not acceptable, or
(b) the Owner has not performed all of its obligations under the terms of this
Agreement to the satisfaction of the Town,
the Town's Director of Public Works shall determine, in his sole discretion, whether a
further rectification period will be granted, and, if so, upon what terms and conditions,
or whether the Town shall proceed under the provisions of section 19, or both.
21. PERFORMANCE AND MAINTENANCE SECURITY
(1) Before this Agreement will be executed by the Town, the Owner shall f'de with the
Town an in'evocable letter of credit, issued by a chartered bank in Canada in the form
set out in Schedule B and in an amount established by the Director of Public Works (the
"original value"), as a performance and maintenance security for the purpose of,
(a) guaranteeing the satisfactory construction, installation or performance of the
Works;
-8-
(b) guaranteeing the payment of any amounts payable to the Town under this
Agreement;
(c) guaranteeing the payment of any amount that the Town may be required to pay
under the provisions of the Construction Lien Act, or any successor thereto, and
(d) guaranteeing all Works, workmanship and materials during the maintenance
period and any rectification period or periods and until a Final Acceptance
Certificate has been issued by the Town's Director of Public Works.
(2) The Owner may, at any time after the first 50 per cent, in value, of Works have been
constructed, installed or performed, and paid for, apply for a reduction in the security
and such application shall be made to the Town Treasurer.
(3) Upon written verification from the Director of Public Works that the construction,
installation or performance of the Works for which reduction is being sought have been
satisfactorily completed and paid for, the Town Manager may reduce the amount of the
security to an amount not less than,
(a) 60 per cent of the original value where no certificate or declaration of
substantial performance has been made;
(b) 35 per cent of the original value where,
(i) a certificate or declaration of substantial performance has been
published;
(ii) 45 days following such publication have expired; and
(iii) all liens that may be claimed against any holdback required to be
retained by the Town have expired or have been satisfied, discharged
or provided for by payment into court;
and
(c) 17 per cent of the original value where,
(i) a certificate of final completion has been made by the Owner's
Consulting Engineer;
(ii) 45 days following the making of such certificate have expired;
(iii) all liens that may be claimed against any holdback required to be
retained by the Town have expired or have been satisfied, discharged
or provided for by payment into court; and
(iv) a Completion Acceptance Certificate has been issued by the Town's
Director of Public Works,
which 17 per cent portion shall secure the guarantee of Works, workmanship
and materials, until a Final Acceptance Certificate has been issued by the
Town's Director of Public Works, when the balance of the security shall be
returned to the Owner subject to any deductions for rectification of deficiencies.
(4) Upon the approval, if any, of a reduction in the amount of the security required to be
provided in subsection (1), the Town Manager or the Town Treasurer shall provide to
the Owner any necessary assurance to effect the reduction.
22. OWNER'S GENERAL INDEM2XlITY
Until the Town's Director of Public Works has issued the Final Acceptance Certificate for the
Works, the Owner shall indemnify the Town against all actions, causes of action~, suits, claims
and demands whatsoever, which may arise either directly or indirectly by reason of the Owner
undertalclng the project or servicing the Lands as required under this Agreement.
-9-
23. QCCUPATIONAL HEALTH AND SAFETY
(1) The Owner certifies that it is aware of its duties and obligations under the Occupational
Health and Safety Act, or any successor thereto, and all Regulations thereunder (herein
called the "Act"), and shall ensure that its employees, contractors, subcontractors and
their employees,
(a) _ are aware of their respective duties and obligations under the Act, and
(b) have sufficient knowledge and training to perform all works and services
required pursuant to this Agreement safely and in compliance with the Act.
(2) In the performance of all works and services required pursuant to this Agreement, the
Owner shall,
(a) act safely and comply in all respects with the Act, and
(b) ensure that its employees, contractors, subcontractors and their employees act
safely and comply in all respects with the Act.
(3) The Owner shall rectify any unsafe act or practice and any non-compliance with the Act
immediately upon being notified by any person of the existence of such act, practice or
non-compliance.
(4) The Owner shall permit representatives of the Town on the she where any works or
services required pursuant to this Agreement are being performed at any time or times
for the purpose of inspection to determine compliance with this section.
(5) No act or omission by the Town or any representative of the Town (including the
entering into of this Agreement) shall be deemed to be an assumption of any of the
duties or obligations of the Owner, its employees, contractors, subcontractors and their
employees under the Act.
(6) In addition to the Owner's general indemnification of the Town pursuant to section 22,
above, the Owner shall indemnify and save harmless the Town,
(a) from any loss, inconvenience, damage or cost to the Town which may result
from the Owner or any of its employees, contractors, subcontractors and theix
employees failing to act safely or to comply in all respects with the Act in the
performance of any work or service required pursuant to this Agreement; and
(b) against any actioh or claim, or costs related thereto, brought against the Town
by any person arising out of any unsafe act or practice or any non-compliance
with the Act by the Owner or any of its employees, contractors, subcontractors
and their employees in the performance of any work or service required
pursuant to this Agreement.
24. LIABILITY ][NSLrRANCE POLICY / PROVISION FOR DEDUCTIBLE
(1) Before this Agreement will be executed by the Town, the Owner shall file with the
Town a Certificate of Insurance verifying that a Liability Insurance Policy is in effect,
setting out the essential terms and conditions of the insurance, and naming the Town as
additional named instLred, all of which shall be subject to the approval of the Town
Solicitor.
(2) The policy shall comply with the following provisions:
(a) the minimum limit per occurrence shall be $5,000,000 all inclusive for property
damage and personal liability;
(b) it shall not contain a clause for exclusion for blasting; and
(c) it may not be cancelled un~ess prior notice by registered letter has been given to
the Town by the insurer thirty days in advance of the expiry date.
-I0-
(3) The policy premium must be paid initially for a period of one year and the policy shall
be renewed for further one year periods until the Final Acceptance Cerfificale has been
issued by the Town's Director of Public Works.
(4) If the Policy coverage is subject to a deductible amount, the Owner shall fie with the
Town, when filing the Certificate of Insurance, a certified cheque or letter of credit with
the Town in the deductible amount, as a deposit, together with a letter from the Owner
authorizing the Town to appoint an independent adjuster and to investigate claims less
than the deductible amount and authorizing the Town to pay such claims deemed valid
by the adjuster out of the deposit; the Owner shall be responsible for all adjustment
service costs and shall maintain the deposit throughout the term of this agreement in the
amount of the deductible.
(5) The provision of the insurance policy required by this section shall not relieve the
Owner from liability for claims not covered by the policy or which exceed its limits, if
any, for which the Owner may be held responsible.
PART $ - DEVELOPING THE PROJECT
25. CONSTRUCTION AND OCCUPANCY OF BUILDINGS
(l) No building permit shall be issued for any building or part of a building on the Lands
until,
(a) all buildings and su'uctures on the Lands prior to draft plan approval have been
demolished by the Owner;
(b) sewer and water facilities are available, and in the opinion of the Town's
Director of Public Works, capable of providing adequate service;
(c) an asphalt base has been laid on the road immediately in front of the building
or part thereof and extended to an existing maintained road; and
(d) the Owner has paid to the Town the applicable development charge for each
dwelling in that building or part thereof in accordance with By-law 3854/91,
enacted pursuant to the Development Charges Act.
(2) No building or part of a building on the Lands shall be occupied except upon the
issuance of a municipal oc'cupancy permit.
(3) No application for a municipal occupancy permit for a building or part of a building
shall be made except upon the following conditions:
(a) storm sewer, sanitary sewer and water facilities are installed and in operation to
adequately serve such building or part thereof;
(b) electric service is completed and in operation; and
(c) such curbs, as in the opinion of the Town's Dixector of Public Works, are
required to be completed prior to occupancy have been constructed on the road
immediately in front of the building or part thereof and extended to an existing
maintained public road.
(4) The Owner shall maintain vehicular access to all occupied buildings on the Lands until
the roads in the plan are formally assumed by the Town.
26. DESIGN PLANNING - RESIDENTIAL UNITS AND NOISE ATTENUATION STRUCrURES
(1) ~ Prior to the issuance of any building permit for the construction of any residential unit
on the Lands and the construction of any noise attenuation structure in or adjacent to the
project, the Owner shall submit to the Town's Director of Planning, for approval, a
report outlining siting and architectural design objectives for the project.
-11-
(2) That report may be required, at the Director's option, to provide the following
information:
(a) house massing;
(b) streetscape;
(c) exterior materials and colours;
(d) architectural style;
(e) visual variety;
(f) energy conservation measures; and
(g) any other data or information reasonably required.
(3) Prior to the issuance of each building permit for the construction of a residential unit on
the Lands, the Owner shall submit to the Town's Director of Planning, for approval, site
plans and architectural drawings for that unit.
(4) Those plans and drawings may be required, at the Director's option, to provide the
following information:
(a) the location of all buildings and structures to be erected and the location of all
facilities and works associated therewith;
(b) the location of landscaping features, including trees to be preserved;
(c) streetscape for front, rear and flankage elevations at a scale acceptable to the
Director;
(d) streetscape to show all street furniture and vegetation;
(e) the relationship of buildings by blocks; and
(f) any other data or information reasonably required.
27. SPECIFIC PROVISIONS RESPECTING DEVELOPMENT
The Owner shall comply with any specific provisions respecting the development of this project
set out in Schedule D.
PART 4 - FITgANCIAL ~
28. EXPIRY OF SECUR_VFIES
(1) Should any letter of credit security required to be provided hereunder expire before the
Town releases the Owner from the terms and conditions hereof, the Owner shall provide
to the Town at least 30 days in advance of the expiry date of that security, a further
security to take effect upon the expiry.
(2) Such further security shall be in a form and amount satisfactory to the Town.
(3) Should no such further security be provided as required, then the Town shall have the
right to convert the expiring security into cash and hold the cash in lieu of and for the
same purposes as the expiring security.
29. PAYMENT OF LIENS AND OTHER CLAIMS
(1) The Owner shall discharge or vacate any liens or claims filed with the Town or
registered on title to any Town-owned lands within thirty days of being requested to do
so by the Town.
(2) At the end of the maintenance period, as extended during any rectification period, the
Owner shall file with the Town a Statutory Declaration stating that,
(a) all materials have been supplied and all services and works have been
completed in the project with respect to the construction and installation of
Works and other services;
(b) all accounts for work or service performed and materials placed or fumisbed
upon or in respect of the construction and installation of Works and other
services in the project have been fully paid and satisfied and no person is
entitled to claim a lien under the Construction Lien Act against the Town or
any Town-owned land;
-12-
(c) there are no judgments or executions fried against the Owner;
(d) nothing is owed by the Owner or claimed against it for unemployment
insurance deductions, income tax deductions, or by way of contribution or
assessment under the Workers' Compensation Act;
(e) the Owner has not made any assignment for the benefit of creditors, nor has
any receiving order been made against it under the Bankruptcy Act, nor has any
petition for such an order been served upon the Owner;, and
(f) 45 days have passed since the completion of the construction, installation, and
last rectification of the Works and services.
30. PAYMENT OF INTEREST ON OVERDUE AMOUNTS PAYABLE
The Owner shall pay interest at the rate of 18 per cent per year to the Town on all sums of
money payable hereunder which are not paid on the due dates calculated from such due dates.
31. PAYMENT OF REALTY AND BUSINESS TAXES / LOCAL IMPROVEMENT CHARGES
(1) The Owner shall pay in full as they come due all realty and business taxes assessed
against the Lands or the Owner as required by law from time to time.
(2) ' Before this Agreement will be executed by the Town, the Owner shall commute and pay
to the Town or to the Regional Municipality of Durham all local improvement charges
assessed against the lands in the plan.
32. PAYMENT OF DEVELOPMENT CHARGES
(1) The Owner shall pay to the Town, in accordance with the Development Charges Act and
the Town's Development Charges By-law 3854/91, development charges for each
dwelling unit within the project respecting the following services:
(a) administrative services - town offices;
(b) administrative services - capital growth studies;
(c) protection -ftre facilities;
(d) protection - fire vehicles and equipment;
(e) storm drainage, roads, sidewalks, storm sewers, lighting and other services;
(0 transportation - works yards, vehicles and equipment;
(g) transportation - transit;
(h) parks - parkland acquisition;
(i) parks - parkland development;
(j) major recreational facilities - major indoor recreational facilities;
(k) library - library facilities;
(1) library - library materials; and
(m) electrical distribution services and facilities.
(2) The amount of the development charge for each dwelling to be erected in the plan shall
be the amount set out in Schedule C for that type of dwelling, as adjusted annually in
accordance with Schedule C.
(3) Where a development charge is payable for a dwelling located on a parcel of land
comprised of land in this plan and land not in this plan, the amount of the development
charge payable for that dwelling shall be the amount calculated in accordance w~th the
provisions of the subdivision agreement for the most recently registered of the plan or
plans within which the parcel is located.
33. PAYMENT OF ENGINEERING. LEGAL AND REGISTRATION FEES
(1) Before this Agreement witl be executed by the Town, the Owner shall pay by certified
cheque to the Town an Engineering Drawing Inspection Fee in the amount set out in
Schedule C for the examination and inspection done by the Town's Public Works
Department in the processing of the engineering drawings for this project.
-13-
(2) Before this Agreement will be executed by the Town, the Owner shall pay by certified
cheque to the Town a Subdivision Agreement Processing Fee in the amount set out in
Schedule C for the preparation and processing of this Agreement by the Town's LegaJ
Services Department.
(3) The Owner shall pay all registration costs incurred by the Town relating in any way to
the registration of the plan of subdivision, this Agreement, or any other documentation,
including transfers, in the Land Registry Office within 30 days of invoices being
rendered.
PART 5 - TRANSFERS AND REGIYl~DITION$
34. TRANSFERS OF LANDS OR INTERESTS IN LANDS OR PAYMENTS IN LIEU THEREOF
(I) Upon executing this Agreement, the Owner shall convey or cause to be conveyed to the
Town, free and clear of all encumbrances and at no cost to the Town, all of the lands or
interests in lands identified in Schedule A for the purposes set out therein.
(2) The Owner hereby warrants that, upon such conveyance, neither the title to the lands
conveyed nor theix physical state and condition shall prevent the Town from lawfully or
physically using the lands for the purposes for which they are being conveyed as set out
in Schedule A.
(3) Where none of the lands identified in Schedule A are to be conveyed for parkland
~hurposes, the Owner shall pay to the Town, before this Agreement will be executed by
e Town, an amount calculated in accordance with the provisions of Schedule A in lieu
of a parkland conveyance.
(4) Any Transfer/Deed given pursuant to this Agreement shall be in a form acceptable to
the Town Solicitor and any Transfer/Deed of a storm drainage works easement shall
contain the Storm Drainage Works Easement Schedule set out in Schedule A.
(5) The Town may complete or alter any description of land in this Agreement or in any
Transfer/Deed given pursuant to this Agreement so as to make the description
correspond with the description of the land according to the plan which is to be
registered pursuant to this Agreement.
35. RELEASE OF THE PLAN FOR REGISTRATION
Before the Town will advise the Regional Municipality of Durham that the conditions of Draft
Approval affecting the Town have been satisfied, the Owner shall deliver to the Town the
following:
(a) four red-lined copies of this Agreement executed by the Owner and all Encumbrancers;
(b) all monies, securities and insurance required by this Agreement;
(c) three executed copies, in a form suitable for registration, of each Transfer/Deed required
by section 34 respecting the conveyances identified in Schedule A, and one draft copy
of each required reference plan.
36. REGISTRATION OF AGREEMENT
(1) This Agreement shall be registered by the Town in the Land Registry Office for the
Land Titles Division of Durham (No. 40).
(2) The Owner shall give to every purchaser of the Lands or any part of the Lands actual
notice of the existence and t~e terms of this Agreement and shall include an
acknowledgement in any offer to purchase or other similar document dealing with the
Lands, or any paxt of them.
(3) The Owner shall indemnify and save harmless the Town from any loss, inconvenience
or damage which may result to the Town from the Owner's failure to comply with
subsection (2) and against any action or claim made against the Town by any person
other than the Owner arising out of the execution by the Town of this Agreement.
-14-
(4) The Owner shall execute such further assurances of the fights hereby granted as may be
deemed necessary by the Town.
IN WITNESS WHEREOF the Parties hereto have hereunto affLxed their respective Corporate Seals
attested to by the hands of their authorized officers.
SIGNED, SEALED AND DELIVERED
668390 ONTARIO LTD.
William $. Daniell, President
In the presence of
ROBERT LEE
(Seal)
JOYCE LEE
THE CORPORATION OF THE TOWN OF PICKERING
Wayne Arthurs, Mayor
Brace Taylor, Clerk
ENCUMBRANCER - CIBC MORTGAGE CORPORATION
The Encumbrancer hereby postpones any rights or interests which it has in the Lands with the intent that
this Agreement shall take effect as though executed and registered prior to the creation of any such right
or interest and prior to the execution and registration of any mot/gage, agreement or other document
creating or defining any such right or interest;
And the Encumbrancer hereby covenants and agrees with the Town that this Agreement and any
conveyance, easement or other document given pursuant to this Agreement, shall have priority over the
rights of the Encumbrancer in thc Lands with the intent that thc Encumbrancer or anyone claiming
under it shall at no time exercise in relation to the Lands any right, title or claim which could not be
exercised by the Owner by reason of the terms of this Agreement.
Dated at , this day of ,1993.
SIGNED, SEALED AND DELIVERED
CIBC MORTGAGE CORPORATION
- 15 -
ENCUMBRANCER - THE ROYAL BANK OF CANADA
The Encumbrancer hereby postpones any rights or interests which it has in the Lands with the intent that
this Agreement shall take effect as though executed and registered prior to the creation of any such right
or interest and prior to the execution and registration of any mortgage, agreement or other document
creating or def'ming any such right or interest;
And the Encumbrancer hereby covenants and agrees with the Town that this Agreement and any
conveyance, easement or other document given pursuant to this Agreement, shall have priority over the
rights of the Encttmbrancer in the Lands with the intent that the Encumbrancer or anyone claiming
under it shall at no time exercise in relation to the Lands any right, title or claim which could not be
exercised by the Owner by reason of the terms of this Agreement.
Dated at , this day of ,1993.
SIGNED, SEALED AND DELIVERED
THE ROYAL BANK OF CANADA
-16-
TRAIgSFE. R~ OF LAItD$ OR IIR'I'F_.RF_3'~ 1~ LA3ID$ OR PAI'MFAVl~ 13I LIEtI ~IF_.REOF
(Section 34)
1. CONVEYANCES REQUIRED TO BE MADE TO THE TOWN
~ parco, se ~
Block 41 Fire hydrant access Easement
Block 42 Pinegrove Avenue reserve Fee simple
Block 43 Pinegrove Avenue reserve Fee simple
Block 44 Rockwood Drive reserve Fee simple
Block 45 Rockwood Drive reserve Fee simple
Lot 5 - 4.5 metre wide strip Storm drainage works Easement
along northern boundary
Lot 6 - 4.5 metre wide strip Storm drainage works Easement
along southern boundary
Lot 14 - 1.5 metre wide str~p Storm drainage works Easement
along western boundary
Lot 15 - 1.5 metre wide strip Storm drainage works Easement
along western boundary
Lot 16 - 1.5 metre wide stop Storm drainage works Easement
along western boundary
Lot 17 - 1.5 metre wide strip Storm drainage works Easement
along eastern boundary
Lot 22 - 4.5 metre wide strip Storm drainage works Easement
along southern boundat7
Lot 23 - 4.5 metre wide strip Storm drainage works Easement
along northern boundary
Lot 27 - 1.5 metre wide strip Storm ~ainage works Easement
along western boundary
Lot 28 - 1.5 metre wide strip Storm drainage works Easement
along eastern boundary
Lot 30 - 3.0 metre wide strip Storm drainage works Easement
along western boundary
Any other portion of the Lands Storm drainage works Easement
determined by the Town's
Director of Public Works
Any lands outside the Lands Storm drainage works Easement
determined by the Town's ~
Director of Public Works
2. CALCULATION OF AMOUNT PAYABLE IN LIEU OF PARKLAND CONVEYANCE
(1) The Owner shall obtain a written appraisal, prepared by a professional land value
appraiser acceptable to the Town, of the value of all the land in the plan as of November
2, 1992.
(2) The amount payable in lieu of a parkland conveyance shall be a sum equal to five per
cent of that value.
STORM DRAINAGE WORKS EASEMENT REFERENCE PLANS
(1) Before the Town will advise the Regional Municipality of Durham that the conditions
of Draft Approval affecting the Town have been satisfied, the Owner shall obtain and
deliver to the Town one draft copy of each proposed reference plan required to effect
the conveyance of the specific easements referred to in section 1 of this Schedule.
(2) Upon the completion of the construction and installation of the storm drainage woi'ks
within each easement shown on any proposed reference plan, the Owner's Consulting
Engineer shall advise the Town's Director of Public Works of the actual location 'of the
works in relation to the proposed easement or easements, and ff the Director is satisfied
with the actual location of the works, the Owner shall register that reference plan and
provide four copies of the plan as registered to the Town Solicitor.
(3) If the Town's Director of Public Works is not satisfied with the actual location of the
works in relation to the proposed easement or easements, the Owner shall obtain and
deliver to the Town one draft copy of a revised proposed reference plan, and the
provisions of subsection (2) and of this subsection will continue to apply.
(4) Where the Town's Director of Public Works determines that the Town requires
easements not specifically referred to in section I of this Schedule, the Owner shall
obtain and deliver to the Town one draft copy of each proposed reference plan required
to effect the conveyance of the such easements within 30 days of the Town's request to
do so, and the provisions of subsections (2) and (3) will apply.
4. STORM DRAINAGE WORKS EASEMENT SCHEDULE
Where a conveyance of an easement is for storm drainage works purposes, the following
Schedule shall be attached to the Transfer/Deed of Easement:
(7) INTEREST/ESTATE TRANSFERRED
Subject to the following terms and conditions, the free, uninterrupted and unobstructed right and
easement to lay, construct, operate, maintain, inspect, alter, repair, relplace, reconstruct and
remove storm drainage works together with appurtenances thereto (berem called the "works"),
in, over, along, across, upon and under the land described in Box 5 (herein called the "lands"),
and to drain storm water in, over, along, across, upon and under the lands, together with the right
to the Transferee, its servants, agents and contractors with all necessary vehicles, supplies and
equipment to enter onto the lands and pass and repass over the lands for the pm, pose of
exercising or enjoying any of the rights granted herein.
The terms and conditions which the parties hereto covenant and agree to observe and be bound
by are as follows:
1. The Transferee shall, except in case of emergency, before commencing any work
authorized hereby, give to the Transferor forty-eight hours previous written notice
thereof, and in cases of emergency such previous notice thereof as is reasonably
possible.
2. Upon completion of any work, the Transferee shall FR1 in all excavations, restore fences,
and restore the surface of the ground by restoring all topsoil and grass cover disturbed
thereby, and do necessary grading to ensure soil and slope stability, and remove all
equipment.
3. The Transferor shall not erect any building or structure (except a fence) on the lands,
and shall not place or remove any fill on or from any part of the lands without the
previous written consent of the Transferee.
4. The right and easement granted herein shall be subject to all leases, licences, and any
rights of use or occupation existing at the date hereof, and the Transferor may from time
to time renew or extend these or make new ones, so long as they do not interfere
unreasonably with the right and._easement herein granted.
5. The Transferor hereby releases the Transferee from any claim which may arise out of
the exercise by the Transferee of the right and easement granted hereby or which may
arise out of the existence of the storm water or the existence, operation or non-operation
of the storm drainage works provided the Transferee has complied with all of the terms
and conditions herein.
- 18-
6. Thc Transferor shall execute such further assurances of the right and easement granted
hereby as the Transferee may reasonably request in writing.
7. The burden of this Transfer and of all the terms and conditions contained herein shall
mn with the lands.
8. This Transfer and all of the terms and conditions comained herein shall enure to the
benefit of and be binding upon the Transferor and the Transferee and their respective
heirs, executors, administrators, successors and assigns.
LAND BENEFrI'rED (DOMINANT TENEMENT)
9. The benefit of this Transfer and all of the terms and conditions contained herein shall
run with all other lands and interests in lands owned, occupied or used by the Transferee
for the purpose of operating and maintaining storm drainage works.
-19-
REQUII~F.D FORM FOR PERFORMAIVCE AND MAIlqT~ANCE SECURITIr LETI'ER OF CREDIT
(Section 21)
To: The Corporation of the Town of Pickering
Picketing Civic Centre
One The Esplanade
Pickering, Ontario
LIV 6K7
We hereby authorize you to draw on Iname of bank], Iaddres~ of bank], for account of Inatne of
company or companies obtaining ~.ecurity] up to an aggregate amount of [amount of security in figures
and in full] available by drafts at sight for ][00% of demand as follows:
Pursuant to the request of our customers(s), the said [name of company or companies obtaining
security], we [name of bank], [address of bank], hereby establish and give to you an irrevocable Letter
of Credit in your favour in the total amount of [amount o/security in numbers and in words] which may
be drawn on by you at any time and from time to time upon written demand for payment made upon us
by you which demand we shall honour without enquiring whether you have a right as between yourself
and our said customer(s or any of them) to make such demand, and without recognizing any claim of
our said customer(s or any of them).
Provided, however, that you are to deliver to [name of bank], [addrgxs of bank], at such time as a
written demand for payment is made upon us a certificate signed by you agreeing or confuming that
monies drawn pursuant to this Letter of Credit axe payable to you or are to be or have been expended
pursuant to obligations incurred or to be incurred by you with reference to your file regarding a
Subdivision Agreement dated [date of Agreement], between [name of signatories to Agreement, other
than Town and Encumbrancer($)] and The Co~puration of the Town of Picketing; this Letter of Credit is
given as the Performance and Maintenance Security required by section 21 of that Agreement.
Partial drawings are permitted.
The amount of this Letter of Credit shall be reduced from time to time as advised by notice in writing
given to us from time to time by you.
This Letter of Credit will continue up to and including [date of expiry of Letter of Credit] and will
expire on that date and you may call for Oayment of the full ainount outstanding under this Letter of
Credit at any thne up to the close of business on that date. It is a condition of this Letter of Credit that it
shall be deemed to be automatically extended for one year from the present or any future expiration date
hereof, unless thirty days lprior to any such date, we shall notify you in writing by registered mail that
we elect not to consider this Letter of Credit renewed for any such additional l~riod.
We hereby covenant with drawers, endorsers, and bona fide holders of drafts drawn under and in
accordance with the terms of this credit that such drafts will be duly honoured if drawn and negotiated
on or before [date of expiry of Letter of Credit].
Thc drafts drawn under this credit are to be endorsed hereon and shall state on their face that they are
drawn under [name of bankl, [address of bankl.
DATED this day of ,19
Instructions for completing Letter of Credit:
I. Letter of Credit must be typed on bank letterhead.
2. Information required in square brackets must be provided where imticated, without brackets.
3. Phrases shown in round brackets must be included without brackets where there are two or
more companies comprising the customer.
4. The date in the sixth paragraph must be at least one year from the date of the Letter of Credit.
The date in the seventh paragraph must be the same as the date in the sixth paragraph.
6. Bank signatories must show name, printed or typed, and title, in addition to signature.
- 20 -
DEVELOPMI~IT CHARGES, ENGI~IF. FRING AND LEGAL
(Sections 32 and 33)
1. I)EVELOPMENT CHARGES PAYABLE
(I) Until and including October 7, 1993, the development charge payable under the Town's
Development Charges By-law 3854/91 for each dwelling unit within this project is
$4,691.
(2) From and after October 8, 1993, the development charge payable for each dwelling unit
within this project will be as set out in subsection (1) as adjusted on October 8, 1993,
and annually on every October 8 thereafter until they are paid, in accordance with the
Engineering News Record Cost Index (Toronto).
(3) The development charge set out in subsection (1) has been derived as follows:
administrative services - town offices $355
administrative services - capital growth studies 80
protection - fire facilities 87
protection - fire vehicles and equipment 145
storm drainage, roads, sidewalks, storm sewers, lighting and other services 907
transportation - works yards, vehicles and equipment 193
transpot~tion - transit 49
parks - parkland acquisition 374
parks - parkland development 775
major recreational facilities - major indoor recreational facilities 814
library - library facilities 216
library - library materials 133
electrical distribution services and facilities 563
total $4,691
2. ENGINEERING DRAWING INSPECTION FEE PAYABLE
The amount of the Engineering Drawing Inspection Fee payable for this project is $1,330.
3. SUBDIVISION AGREEMENT PROCESSING FEE pAYABLE
The amount of the Subdivision Agreement Processing Fee payable for this Agreement is $2,000
plus $140 GST.
-21 -
SPECIFIC PROVISIONS RF_~P~G DEVI~Z~PMENT
(Section 27)
1. EXPECTED NUIVIBER OF DWELLINGS
(1) This Agreement has been entered into in the expectation that 38 dwellings axe to be
constructed on the Lands, one each on Lots 1 to 38.
(2) If more or less than 38 dwellings are to be constructed in this project, the Town at its
sole discretion may require the Owner to obtain new approvals and authorizations under
this Agreement and may prohibit any development until the new approvals and
authorizations are obtained.
2. RESERVED FUTURE DEVELOPMENT BLOCKS - BLOCKS 39. 40 AND 41
(1) Blocks 39 and 40 shall be reserved for future residential development; such
development shall not commence without the prior written approval of the Town which
may be subject to conditions.
(2) Block 41 shall be reserved for future roadway development; such development shall not
commence without the prior written appruva~ of the Town which may be subject to
conditions.
(3) Until such time as Blocks 39, 40 and 41 are developed in accordance herewith, the
Owner shall maintain them in a clean and orderly condition to the satisfaction of the
Town.
3. CONTRIBUTION BY OWNER TO TOWN COSTS OF SHARED SERVICES
Before this Agreement will be executed by the Town, the Owner shall pay by certified cheque to
the Town,
(a) the sum of $2,188, being the Owner's pro-rated contribution to the Town's cost of the
installation of grade crossing controls at the grade crossing of the C.N.R. right-of-way
on Woodview Avenue north of Twyn Rivers Drive, and
(b) the sum of $2,668, being the Owner's pro-rated contribution to the Town's cost of the
construction of the Petticoat Creek Stormwater Management Pond,
which facilities benefit the lands in this plan.
4. CONTRIBUTION BY OWNER TO OTHERS' COSTS OF SHARED SERVICES
Before this Agreement will be executed by the Town, the Owner shall provide to the Town,
(a) a certified cheque payable to Danlu Holdings Limited, Perdanco Holdings Ltd., and
/nperdel Holdings Limited, collectively known as Altona West Developments, in the
amount of $8,814, being the Owner's pro-rated contribution to those companies' cost of
the acquisition of the Petticoat Creek Stormwater Management Pond and access
easement;
(b) a certified cheque payable to Nugget Construction Co. Ltd. in the amount of
$ , being the Owner's pro-rated contribution to that company's cost
of the oversizing of stormwater management facilities in Plan 40M- 1630, Picketing;
(c) a certified cheque payable ~o Alastair MacKay Realty Inc. in the amount of $4,933,
being the Owner's pro-rated contribution to that company's cost of the acquisition of
the Altuna Stormwater Management Pond; and
(d) a certified cheque payable to Meadowcliffe Homes in the amount of $10,387, being the
Owner's pro-rated contribution to that company's cost of the construction of the Altona
Trunk Storm Sewer,
which facilities benefit the lands in this plan.
- 22 -
5. CONTRIBUTIONS BY OTHERS TO OV~NER'S COSTS OF SHARED SERVICES
(1) Within 60 days of the acknowledgement, by the Town's Director of Public Works, of
the completion of the storm sewer, road, curbs and gutters and street lighting in or on
Rockwood Drive as provided for in this Agreement, the Owner's consulting engineer
shall provide to the Town, in a form satisfactory to the Town, a detailed summary of the
actual cost, to the Owner, of the design and construction or installation of the storm
sewer, road, curbs and gutters and street lighting.
(2) Within 30 days of the receipt by the Town of the summary referred to in subsection (I),
in a form satisfactory to the Town, the Town Manager shall determine and notify the
Owner, in writing, of the following:
(a) those lands abutting Block 44 or Block 45 outside the plan of subdivision that
the works shall be deemed to benefit (the "benefitting lands") for the purposes
of this section and the conditions, if any, under which such lands shall continue
to be benefitting lands;
(b) the portion of the Owner's actual cost, referred to in subsection (1), that the
Town shall deem to be applicable to the benefitting lands (the "shared cost")
for the purposes of this section; and
(c) the method or methods that shall be employed to pro-rate the shared cost to the
benefitting lands,
and that determination shall be final.
(3) In the event that the benefitting lands, or any part thereof,
(a) are to be developed by plan of subdivision, plan of condominium or any other
method requiring a Development Agreement, or
(b) require access to Rockwood Drive necessitating the dedication as public
highway of all or a part of either Block 44 or Block
then the Town shall endeavour to ensure that the owner thereof pays to the Owner
herein, prior to such development or dedication, all or an appropriate portion of the
shared cost,
(c) calculated according to the method or methods referred to in subsection (2), and
(d) adjusted annually, for a maximum of five years from the date of notification
referred to in subsection (2), according to the Southam Construction Cost Index
for Ontario, composite portion.
(4) In consideration of the Town recommending this plan of subdivision for approval and
entering into this Agreement with this section included, the Owner hereby,
(a) remises, releases and forever discharges, and
(b) agrees to indemnify and save harmless, the Town, /ts officers and employees
and their respective heirs, executors, administrators, successors and assigns, of
and from all actions causes of action, accounts, claims, debts, damages,
demands, and costs associated therewith, arising, to arise or which may
hereafter be brought against them, or any of them, by or on behalf of the
Owner, or any other person, because of the provisions of this section or any
error, omission, failure or negligence in the application thereof.
6. WOODVIEW AVENUE / PBqEGROVE AVENUE CONSTRUCTION
(1) Without limiting the generaliW of the requirements of section 10 of this Agreement, the
~_ Owner shall include among the works and services to be constructed and installed by it
the following:
(a) on Woodview Avenue between the easterly extension of the southern boundary
of the Lands and thc easterly extension of the northern boundary of Plan
40M-1692 (approximately) - a roadway (com. plete with all signs and other
appurtenances), a storm sewer (complete with curbs, gutters, catchbasins,
manholes and laterals), a sidewalk, boulevard restoration and driveway
restorations;
- 23 -
on that part of Lot 9, Plan 252, Picketing, designated a~ Parts 21, 22 and 23,
Plan 40M-1120~, between Woodview Avenue and O~bum Street - a storm
sewer (complete with manholes);
(c) on Woodview Avenue between Pinegrove Avenue and the easterly extension of
the southerly boundary of the Lands - a roadway (complete with all signs and
other appurtenances), a storm sewer (complete with curbs, gutters, catchbasins,
manholes and laterals), a sidewalk, boulevard restoration, driveway
restorations and street lighting;
(d) on Pinegrove Avenue between the northerly extension of the western boundary
of the Lands and Woodview Avenue - a roadway (complete with all signs and
other appurtenances), a storm sewer (complete with curbs, gutters, catchbasins,
manholes and laterals), a sidewalk, boulevard restoration, driveway
restorations and street lighting; and
(e) on Pinegrove Avenue between Woodview Avenue and Oakbum Street
(approximately) - a roadway (complete with all signs and other appurtenances),
a storm sewer (complete with curbs, gutters, catchbasins, manholes and
laterals), bonlevard restoration and driveway restorations.
(2) Despite the provisions of section 8 of this Agreement (deeming every provision of this
Agreement by which the Owner is obligated in any way to include the words "at the
expense of the Owner and at no expense to the Town" unless the context requires
otherwise), the Town shall pay to the Owner,
(a) all of the Owner's cost of the design, construction and installation of the works
and services referred to in clauses (a), (b) and (e) of subsection (1) of this
section; and
(b) all of the Owner's cost of the design, construction and installation of storm
sewer laterals referred to in clause (c) of subsection (1) of this section; and
(c) all of the Owner's cost of the design, construction and installation of storm
sewer laterals and any oversized portion of storm sewer referred to in clause (d)
of subsection (1) of this section,
as invoices therefor are submitted by the Owner supported by appropriate progress
certificates, certifications and declarations.
SPECIAL PROVISIONS REQUIRED BY THE REGIONAL MUNICIPAIIIT OF DURItAM
The sectionx set out in this Schedule represent provision~ not affecting the Town but required to be
inserted in this Agreement by the conditions of Draft Approval dated November 3, 1992, as amended
April 8, 1993, of Drafi Plan 18T-85006 by the Commissioner of Planning of the Regional Municipality
of Durham (the "Approval").
1. METROPOLrrAN TORONTO AND REGION CONSERVATION ALrrHORITY
CM.T.R.C.A.")
M.T.R.C.A. requires that the Owner carry out or cause to be carried out, to the satisfaction of
M.T.R.C.A., the recomanendations referred to in the report(s) required in Condition 16 of the
Approval.
2. MINISTRY OF NATURAL RESOURCES ("M.N.R.")
M.N.R. requires that the Owner,
(a) carry out or cause to be carried out, to the satisfaction of M.N.R., the works referred to
in Condition 18 of the Approval;
(b) maintain all stormwater management and erosion and sedimentation control structures
operating in good repair during the construction period, in a manner satisfactory to
M.N.R.; and
(c) advise M.N.R. 48 hours prior to commencement of grading or the initiation of any
on-site works.
3. DURHAM BOARD OF EDUCATION
The Durham Board of Education requires that the Owner insert the following clauses [sic] into
the agreement of purchase and sale for each lot:
Students from this develppment may have to attend existing schools even though a
school site has been reserved in at; adjacent development. The school site in the
adjacent development may not be built for some time, if at all, atwl only then if it can be
justified to the Ministry of Education.
- 25 o