HomeMy WebLinkAboutBy-law 5240/98THE CORPORATION OF THE TOWN OF PICKERING
BY-LAW NO. 5240/98
Being a by-law to authorize the execution of a
Subdivision Agreement and related documentation
respecting the development of Part Lot 31, Concession 1,
Pickering [Woodsmere Properties Limited - 18T-96009J.
WHEREAS, the proposal to subdivide and register a plan of subdivision of part of Lot 31, Concession 1,
Picketing, has been approved by the Ontario Municipal Board as Draft Plan 18T-96009, subject to
several conditions, one of which requires the entering into of a satisfactory Subdivision Agreement for
each phase thereof with The Corporation of the Town of Picketing, pursuant to the provisions of the
Planning Act, R.S.O. 1990, chapter P.13 section 51(6); and
AND WHEREAS, pursuant to the provision of the Municipal Act, R.S.O. 1990, chapter M.45, section
191(1) the Council of The Corporation of the Town of Picketing may pass by-laws for acquiring any
land or interest therein for the purposes of the corporation;
NOW THEREFORE, the Council of The Corporation of the Town of Picketing HEREBY ENACTS AS
FOLLOWS:
1. (a)
(b)
The Mayor and Clerk are hereby authorized to execute a Subdivision Agreement
substantially in accordance with the form attached hereto as Schedule A, between
Woodsmere Properties Limited and The Corporation of the Town of Picketing, respecting
the development of part of Draft Plan 18T-96009.
The Corporation of the Town of Picketing shall acquire those lands or interests in the
lands referred to in section 34 and identified in Schedule A of that Subdivision
Agreement subject to the terms and conditions and for the purposes set out therein.
The Mayor and Clerk are hereby authorized to execute Transfers/Deeds of Easement in the form
attached hereto as Schedule B, effecting the acquisition by The Corporation of the Town of
Picketing of any interests in the nature of storm drainage works easements in the land comprising
Draft Plan 18T-96009.
BY-LAW read a first, second and third time and finally passed this 23rd day of March, 1998.
Wayne Arthurs, Mayor
, Clerk
18T-96009
Schedule
THIS SUBDIVISION AGREEMENT made April
Planning Act, R.S.O. 1990, chapter P.13,
/
A
ATTACHMENT#_~ TO REPORT#L_~
6, 1998, pursuant to the.provisions of section 51 of the
BETWEEN:
WOODSMERE PROPERTIES LIMITED
herein called the "Owner"
OF THE FIRST PART,
THE CORPORATION OF THE TOWN OF PICKERING
herein called the "Town"
OF THE SECOND PART.
WHEREAS the Owner proposes to subdivide Part of Lot 31, Concession 1, in the Town of Pickering, in the
Regional Municipality of Durham, and to register a plan of subdivision of those lands, as shown on a draft plan
of subdivision designated as Draft Plan Number 18T-96009, and is required as a condition of approval thereof
to enter into a subdivision agreement with the Town pursuant to section 51 of the Planning Act, R.S.O. 1990,
chapter P. 13;
NOW THEREFORE, THIS AGREEMENT WITNESSETH THAT, in consideration of the Town consenting to
the registration of the proposed plan of subdivision, and the covenants hereinafter expressed, the Parties hereto
covenant and agree one with the other as follows:
PART 1 - INTERPRETING AND APPLYING THIS AGREEMENT
1. LAND AFFECTED
The lands affected by this Agreement (the "Lands") are Lots 1 to 14, inclusive and Blocks 15, 16, 17 and
18, Plan 40M-XXXX, Picketing.
2. STATUS OF THIS AGREEMENT
(1)
(2)
In the event the plan of subdivision is not registered on or before December 6, 1998, this
Agreement shall be null and void and of no further effect, and the Town shall not be liable for
any expenses, costs or damages suffered by the Owner as a result thereof.
This Agreement is entered into and executed by the Owner for the purpose of having the Town
act in reliance on the covenants by the Owner contained herein and the Owner hereby waives any
right or claim which it now has or may hereinafter acquire which is inconsistent with the terms of
this Agreement.
3. INTERPRETATION
(1)
Whenever in this Agreement the pronoun "it" is used, it shall be read and construed as "he",
"she", "they", "him", "her" or "them", and the number of the verb agreeing therewith shall be
construed accordingly.
(2) Schedules A, B, C and D attached hereto shall form part of this Agreement.
(3) Time shall be of the essence of this Agreement.
BINDING PARTIES
This Agreement shall be enforceable by and against the Parties hereto, their heirs, executors,
administrators, successors and assigns, and the Agreement and all the covenants by the Owner contained
herein shall nm with the Lands for the benefit of the Town and the land or interests in land owned by the
Town upon the registration of the plan.
o
NOTICE
(1) Any notice required to be given hereunder may be given by personal delivery or registered mail,
(a) in the case of the Owner, to
Woodsmere Properties Limited
c/o Graywood Developments Ltd.
Box 370
370 King Street West, Suite 500
Toronto, Ontario
M5V 1J3
and
(b) in the case of the Town, to
The Town Clerk
The Corporation of the Town of Pickering
Pickering Civic Complex
One The Esplanade
Pickering, Ontario
L1V 6K7
(2)
Each Party may redesignate the person or the address, or both, to whom or to which such notice
may be given by giving written notice to the other.
(3)
Any notice given in accordance with this section shall be deemed to have been given on the
second day following the day of delivery or the day of mailing, as the case may be.
o
LICENCE TO ENTER
The Owner shall retain a licence from any subsequent purchaser of the Lands, or any part thereof, to
enable the Owner and the Town's inspectors to enter upon the Lands in order to comply with the
provisions of this Agreement.
7. OWNER'S GENERAL UNDERTAKING
The Owner shall complete in a good workmanlike manner for the Town, ail the municipal services as
hereinafter set forth to the satisfaction of the Town, and shall complete, perform or make payment for
such other matters as may be provided for herein.
8. OWNER'S EXPENSE
Every provision of this Agreement by which the Owner is obligated in any way shall be deemed to
include the words "at the expense of the Owner and at no expense to the Town" unless the context
requires otherwise.
PART 2 - CONSTRUCTING THE TOWN'S SERVICES
9. CONSULTING ENGINEERS
(1)
The Owner shail retain a Professional Engineer as the Consulting Engineer of the Owner to carry
out all the necessary engineering and to supervise the work required to be done for the
development and construction of the project.
(2)
Such Consulting Engineer, or any successor thereto, shall continue to be retained until the work
required to be done for the development and construction of the project is completed and
formally accepted by the Town.
(3)
The Owner may change from one Consulting Engineer to another at any time or times during the
development and construction of the project, so long as the Owner has a Consulting Engineer
retained at all times.
10. CONSTRUCTION / INSTALLATION OF TOWN WORKS AND SERVICES
(1)
The Owner shall obtain all required approvais and shall construct or install to Town standards
and shall provide to the Town, complete in every detail, the following Town works and services
(the "Works") as shown on plans submitted by the Owner's Consulting Engineer to the Town and
approved by the Town's Director of Public Works in accordance with the Town's specifications
for such Works:
(a) Town roads within the plan, complete with all signs and other appurtenances;
(b)
Town roads adjacent to the plan and not separated from the plan by a reserve or reserves,
complete with ail appurtenances;
(c)
removai and replacement of any temporary turning circle located immediately adjacent to
the plan on a Town road to be extended into the plan;
(d)
street storm sewers on roads referred to in (a) and (b), complete with curbs, gutters,
catchbasins and manholes;
(e)
storm water drainage and management system serving the lands in the plan and lands
outside the plan but draining through the plan, complete with detention or retention
facilities, quality control devices and outlets;
(0
boulevards and sidewalks on Town roads within the plan, on Town roads adjacent to the
plan but not separated from the plan by a reserve or reserves, and on Town roads to be
extended into the plan where the Owner is required to remove and replace a temporary
turning circle;
(g)
street lighting on Town roads within the plan, on Town roads adjacent to the plan but not
separated from the plan by a reserve or reserves, and on Town roads to be extended into
the plan where the Owner is required to remove and replace a temporary turning circle;
(h)
street tree planting on Town roads within the plan, on Town roads adjacent to the plan but
not separated from the plan by a reserve or reserves, and on Town roads to be extended
into the plan where the Owner is required to remove and replace a temporary turning
circle;
(i)
walkways on walkway blocks and park entrances, complete with walkway fencing and
lighting; and
(j) other fencing, including,
(i)
fencing adjacent to commercial sites, school sites, parks, open space, storm water
management facilities and roads adjacent to the plan and separated from the plan
by a reserve or reserves, and
(ii) noise attenuation fencing.
(2)
If at any time prior to the acceptance of the Works, the Town's Director of Public Works is of the
opinion that additional works are necessary to provide adequately any of the public services
required by the project, the Owner shall construct, install or perform such additional works at the
request of the Director.
(3)
All Works shall be constructed and installed in accordance with the Town's specifications and in
a good and workmanlike manner under the supervision of the Owner's Consulting Engineer and
under the observation of the Town's inspectors or, in the case of street lighting, Pickering Hydro's
inspectors.
(4)
The Owner shall conduct video inspections of
constructed or installed hereby and shall provide
inspections to the Town.
all underground services required to be
a VHS-format videotape record of those
(5)
The Owner shall pay to the Town the Town's costs of inspection, including but not necessarily
limited to, salaries and wages of inspectors, testing fees and administration fees, within 30 days
of invoices being rendered.
11. GENERAL REGULATIONS RESPECTING SERVICING
O)
The construction of Town roads shall include the construction of paved driveway approaches
between the curb and sidewalk or, where no sidewalk is to be provided, between the curb and the
lot line.
(2)
Where the construction or installation of services involves a continuation or extension of existing
services, the Owner shall join into the existing services, including adjustment of grades where
necessary, in a good and workmanlike manner.
(3)
The Owner shall not dump nor permit to be dumped any fill or debris on, nor remove or permit
to be removed any fill from, any public lands, other than in the actual construction of roads in the
project without the written consent of the authority responsible for such lands.
(4)
The Owner shall not bum nor permit to be burned any refuse or debris within the project or
adjacent to it.
(5)
(6)
(7)
(8)
The Town's Director of Public Works may have qualitative or quantitative tests made of any
materials which have been or are proposed to be used in the construction or installation of any
services required by this Agreement, and the cost of such tests shall be paid by the Owner within
30 days of invoices being rendered.
The Owner shall pay, within 30 days of invoices being rendered, the costs of,
(a)
relocating any existing services or utilities required to be relocated by the construction or
installation of Works, services, or utilities in the project; and
(b)
moving any Works, services or utilities installed in driveways or so close thereto, in the
opinion of the Town's Director of Public Works, as to interfere with the use of the
driveway.
Unless otherwise provided herein, the Owner shall perform any work required to be done under
this Agreement to the specifications of the Town in effect at the date hereof.
The Owner shall provide and erect temporary signs of such nature and at such locations as
designated by the Town's Director of Public Works.
12.
ELECTRICAL SERVICES
Where electricity, cable television service or telephone service is to be provided to any lot or block in the
project, it shall be provided underground and in accordance with the standards and specifications of
Picketing Hydro-Electric Commission, Trillium Cable T.V. Limited or Bell Canada, as the case may be.
13.
TREE INVENTORY / TREE PRESERVATION PROGRAM
(1)
The Owner shall submit a Tree Inventory and a Tree Preservation Program prepared by a
qualified expert, and based upon the Town-approved Grading Control Plan, indicating which
existing trees in the project may be preserved to the Town's Director of Planning for the review
and approval of the Town's Director of Planning and Director of Parks and Facilities, and shall
implement the Program as approved only.
(2)
Until the Tree Preservation Program is approved the Owner shall not commence, nor allow to be
commenced, any aspect of the development of the lands in the project, including the removal of
any tree.
(3)
In the event that any tree required to be preserved by the approved Tree Preservation Program is
removed or is, in the opinion of the Town's Director of Parks and Facilities, damaged to such an
extent that its value or longevity is decreased or is likely to be decreased, then the Owner shall
replace that tree with a tree of a height, diameter and species determined by the Director; such
replacement shall be at no cost to the Town.
(4) The Owner's liability under subsection (3) shall continue until,
(a)
where the lands upon which the tree is located comprise a residential building lot or
block, twelve months after the completion of the sodding on the lot or block; or
(b)
where the lands upon which the tree is located comprise lands other than a residential
building lot, the issuance by the Town of the Final Acceptance Certificate.
14.
GRADING CONTROL PLAN / LOT DRAINAGE AND SODDING
(1) The Owner shall submit to the Town, for the approval of the Town's Director of Public Works, a
Grading Control Plan (including a geotechnical soils analysis) prepared by the Owner's
Consulting Engineer, establishing the proposed grading of the lands in the project to provide for
the proper drainage thereof and the drainage of all adjacent lands which drain through the lands
in the project.
(2)
The Grading Control Plan shall be prepared in accordance with the Town's Lot Drainage
Specifications and shall not provide for the drainage of surface mn-off water onto Town-owned
parkland, open space or walkways unless provision is made for the installation by the Owner, at
no cost to the Town, of suitable swales and catch basins to manage adequately, in the opinion of
the Town's Director of Parks and Facilities, that surface run-off water.
(3)
The Owner shall grade all the lands in the project in accordance with the approved Grading
Control Plan, ensuring that sufficient topsoil remains as cover on all areas of the project intended
for sodding, seeding, or other planting.
(4) If the Town determines that,
(a) grading has not been done in accordance with the Grading Control Plan;
(b)
grading has been done in accordance with the Grading Control Plan but drainage
problems remain; or
(c) sufficient topsoil has not been left in the appropriate areas.
the Owner shall re-grade the project, or part thereof affected, adding a sufficient amount of
topsoil if necessary, or construct catch basins, swales or other structures as may be necessary to
correct such problems, as directed by the Town's Director of Public Works.
(5)
The Owner shall sod the front, side and rear yards of each of the residential lots and blocks in the
project except for paved, planted or treed areas prior to the occupancy of the dwelling unit
located thereon or within the six months immediately thereafter except, where the occupancy of
the dwelling unit occurs in November or December of any year, the time limit for sodding may
be extended to June 30 in the following year.
15. AUTHORIZATION TO COMMENCE WORK
The Owner shall not commence the construction or installation of any of the Works without the written
Authorization to Commence Work of the Town's Director of Public Works, which Authorization shall
not be issued until:
(a)
four red-lined copies of this Agreement executed by the Owner and all Encumbrancers have been
provided to the Town to the satisfaction of the Town Solicitor;
(b)
all of the insurance requirements outlined in section 24 together with any securities required by
this Agreement have been provided to the satisfaction of the Town Treasurer and the Town
Solicitor;
(c)
all approvals and permits have been obtained by the Owner from the Ministry of the
Environment, the Ministry of Natural Resources and the Metropolitan Toronto and Region
Conservation Authority, or a certificate has been provided by the Owner's Consulting Engineer
that no such approvals or permits are required, along with all approvals required by this
Agreement;
(d)
conveyance of good title, free and clear of all encumbrances, to the Town, of all necessary
Easements and Transfers of interests in lands lying outside of the Lands as identified in Schedule
A; and
(e)
the Owner's Solicitor has provided, at the Owner's expense, a certificate of clear title, to the
satisfaction of the Town Solicitor, of all the lands and interests of lands conveyed to the Town,
lying outside of the lands, as set out in Schedule A hereto.
6
16. USE OF WORKS PENDING COMPLETION / EMERGENCY REPAIRS
(1)
Any of the Works may be used by the Town, or by such other person or agency as may be
authorized by the Town's Director of Public Works, for the purposes for which the Works are
designed, and such use shall not be deemed an acceptance of any of the Works by the Town, nor
an assumption by the Town of any liability in connection therewith, nor a release of the Owner
from any of its obligations under this Agreement.
(2)
The Town may make emergency repairs at any time to any of the Works and may for this
purpose enter the Lands at any time; such repair or entry shall not be deemed an acceptance of
any of the Works by the Town, nor an assumption by the Town of any liability in connection
therewith, nor a release of the Owner from any of its obligations under this Agreement.
17. INTERNAL / EXTERNAL ROAD MAINTENANCE AND REPAIR / SNOW PLOWING
0)
(2)
Throughout the term of this Agreement, the Owner shall,
(a)
maintain all Town roads within the project in a mud and dust free condition and free of
obstructions, regardless of the source or cause of any mud, dust or obstruction;
(b)
maintain all Town roads outside the project, including boulevards, in a mud and dust free
condition and free of obstructions, where the source or cause of the mud, dust or
obstruction is an operation or operations related in any way to the development of the
project;
(c)
repair all Town roads outside the project, including boulevards, where damage has
occurred as a result of an operation or operations related in any way to the development
of the project; and
(d)
plow snow from and salt all Town roads within the project that are not subject to the
Town's winter control program.
The Owner, within 24 hours of verbal notification by the Town to it or its representatives, shall
undertake such works as are necessary to clean, clear, repair, plow or salt any Town road
requiring such work in the opinion of the Town's Director of Public Works or his designate.
18.
COMPLETION DATES - TOWN WORKS AND SERVICES
(1) The Owner shall complete the Works in accordance with the following time limits:
(a) Town roads within the plan - two years from date of Authorization to Commence Work;
(b)
Town roads adjacent to the plan ~ two years from date of Authorization to Commence
Work;
(c)
removal and replacement of any temporary mining circle - two years from date of
Authorization to Commence Work;
(d) street storm sewers - one year from date of Authorization to Commence Work;
(e)
storm water drainage and management system (including grading and top-soiling of non-
residential lots and blocks) - one year from date of Authorization to Commence Work;
(O(i)
boulevards and sidewalks on Town roads within the plan, on Town roads adjacent to the
plan but not separated from the plan by a reserve or reserves - six months after occupancy
of first dwelling to be occupied adjacent to segment as identified by the Town's Director
of Public Works, but no later than two years from date of Authorization to Commence
Work;
(2)
(f)(ii)
boulevards and sidewalks on Town roads to be extended into the plan where the Owner is
required to remove and replace a temporary mining circle - two years from date of
Authorization to Commence Work;
(g) street lighting - one year from date of Authorization to Commence Work;
(h) street tree planting - two years from date of Authorization to Commence Work;
(i) walkways, walkway fencing and walkway lighting - prior to the occupancy of any
dwelling adjacent thereto;
(j)(i) other fencing adjacent to,
A
parks, open space and storm water management facilities - prior to the occupancy
of any dwelling adjacent thereto;
B commercial sites and school sites - one year from date of Authorization to
Commence Work; and
C
roads adjacent to the plan and separated from the plan by a reserve or reserves -
six months after occupancy of first dwelling to be occupied adjacent to segment as
identified by the Town's Director of Public Works, but no later than two years
from date of Authorization to Commence Work; and
(j)(ii) noise attenuation fencing - prior to the occupancy of any dwelling adjacent thereto,
following the satisfactory completion and testing of all of which, and the approval thereof by the
Town, the Town shall issue to the Owner a Completion Acceptance Certificate.
Despite the provisions of subsections (1)(f)(i) and (1)(j)(i)C, where the occupancy of the first
dwelling unit occurs in November or December of any year, the time limit for construction of the
adjacent boulevard, sidewalk or fencing segment shall be extended to June 30 in the following
year.
19.
FAILURE TO COMPLETE / IMPROPER PERFORMANCE
(1)
If, in the opinion of the Town's Director of Public Works, the Owner is not constructing or
installing the Works, or causing them to be constructed or installed, within the specified time or
so that they may be completed within the specified time, or is improperly performing the Works,
or has neglected or abandoned them before completion, or has unreasonably delayed them so that
the terms and conditions of this Agreement are being violated or executed carelessly or in bad
faith, or has neglected or refused to renew or again perform Works rejected by the Director of
Public Works as defective or unsuitable, or has in any other manner, in the opinion of the
Director of Public Works, defaulted in the performance of the terms and conditions of this
Agreement, then the Director may notify the Owner and his surety in writing of the default or
neglect and if the notification be without effect for seven days, then the Director shall have full
authority to make any payment or do any thing, including but not limited to obtaining materials,
tools and machinery and employing persons required for the proper completion of the Works or
rectification of the default, at the cost and expense of the Owner or his surety, or both.
(2)
In cases of emergency, in the opinion of the Director of Public Works, such Director may act
without prior notice but the Owner and its surety shall be notified forthwith.
(3)
The cost of rectifying the default shall be calculated by the Director of Public Works, whose
decision shall be final, and may be charged to the Owner, together with a 25 per cent engineering
and administration fee, by drawing upon the letter of credit filed with the Town under section 21.
20. GUARANTEE OF WORKS, WORKMANSHIP AND MATERIALS
The Owner shall guarantee all Works, workmanship and materials employed or used in the
construction, installation or completion of Works, services and other requirements under this
Agreement for a minimum period of two years (the "maintenance period") following the issuance
of the Completion Acceptance Certificate by the Town.
(2)
Despite any other provisions of this Agreement, the responsibilities of the Owner during the
maintenance period shall include the maintenance of the Works, including the rectification of any
unsatisfactorily installed Works.
(3)
Prior to the end of the maintenance period, the Owner's Consulting Engineer shall submit to the
Town,
(a)
"as built" construction drawings for the Works complete as per Town standards, together
with that Consulting Engineer's certificate that those drawings accurately depict the
Works as constructed; and
(b)
a statement by an Ontario Land Surveyor that all standard iron bars as shown on the
registered plan, and survey monuments at all block comers, at the ends of all curves
(other than comer roundings) and at all points of change in direction of streets in the plan
have been found or re-established.
(4) Prior to the end of the maintenance period, the Town will re-inspect the Works and if,
(a) the Works are acceptable; and
(b)
the Owner has performed all of its obligations under the terms of this Agreement to the
satisfaction of the Town,
the Town will issue to the Owner a Final Acceptance Certificate at which time the Town will
assume ownership of the Works and the operation and maintenance thereof, and the maintenance
period will then end.
(5) If upon the re-inspection conducted prior to the end of the maintenance period,
(a) the Works are not acceptable; or
(b)
the Owner has not performed all of its obligations under the terms of this Agreement to
the satisfaction of the Town,
the Town will advise the Owner of the deficiencies, the expected rectifications, and the time
limited for implementing the rectifications (the "rectification period") and the maintenance
period shall be extended to the end of the rectification period.
(6) At the end of the rectification period, the Town will re-inspect the Works and if,
(a) the Works are acceptable; and
(b)
the Owner has performed all of its obligations under the terms of this Agreement to the
satisfaction of the Town,
the Town will issue to the Owner a Final Acceptance Certificate at which time the Town will
assume ownership of the Works and the operation and maintenance thereof, and the maintenance
period will then end.
(7) If upon the re-inspection conducted at the end of the rectification period,
(a) the Works are still not acceptable; or
9
the Owner has not performed all of its obligations under the terms of this Agreement to
the satisfaction of the Town,
the Town's Director of Public Works shall determine, in his sole discretion, whether a further
rectification period will be granted, and, if so, upon what terms and conditions, or whether the
Town shall proceed under the provisions of section 19, or both.
21. PERFORMANCE AND MAINTENANCE SECURITY
(1)
Before this Agreement will be executed by the Town, the Owner shall file with the Town an
irrevocable letter of credit, issued by a chartered bank in Canada and in an amount established by
the Director of Public Works (the "original value"), as a performance and maintenance security
for the purpose of,
(a) guaranteeing the satisfactory construction, installation or performance of the Works;
(b) guaranteeing the payment of any amounts payable to the Town under this Agreement;
(c)
guaranteeing the payment of any amount that the Town may be required to pay under the
provisions of the Construction Lien Act, or any successor thereto; and
(d)
guaranteeing all Works, workmanship and materials during the maintenance period and
any rectification period or periods and until a Final Acceptance Certificate has been
issued by the Town's Director of Public Works.
(2)
The Owner may, at any time after the first 50 per cent, in value, of Works have been constructed,
installed or performed, and paid for, apply for a reduction in the security and such application
shall be made to the Town Treasurer.
(3)
Upon written verification from the Director of Public Works that the construction, installation or
performance of the Works for which reduction is being sought have been satisfactorily completed
and paid for, the Town Manager may reduce the amount of the security to an amount not less
(a) 60 per cent of the original value where no certificate or declaration of substantial
performance has been made;
(b) 35 per cent of the original value where,
(i) a certificate or declaration of substantial performance has been published;
(ii) 45 days following such publication have expired; and
(iii)
all liens that may be claimed against any holdback required to be retained by the
Town have expired or have been satisfied, discharged or provided for by payment
into court;
and
(c) 17 per cent of the original value where,
(i) a certificate of final completion has been made by the Owner's Consulting
Engineer;
(ii) 45 days following the making of such certificate have expired;
(iii)
all liens that may be claimed against any holdback required to be retained by the
Town have expired or have been satisfied, discharged or provided for by payment
into court; and
10
(iv)
a Completion Acceptance Certificate has been issued by the Town's Director of
Public Works,
which 17 per cent portion shall secure the guarantee of Works, workmanship and
materials, until a Final Acceptance Certificate has been issued by the Town's Director of
Public Works, when the balance of the security shall be returned to the Owner subject to
any deductions for rectification of deficiencies.
(4)
Upon the approval, if any, of a reduction in the amount of the security required to be provided in
subsection (1), the Town Manager or the Town Treasurer shall provide to the Owner any
necessary assurance to effect the reduction.
22. OWNER'S GENERAL INDEMNITY
Until the Town's Director of Public Works has issued the Final Acceptance Certificate for the Works,
the Owner shall indemnify the Town against all actions, causes of actions, suits, claims and demands
whatsoever, which may arise either directly or indirectly by reason of the Owner undertaking the project
or servicing the Lands as required under this Agreement.
23. OCCUPATIONAL HEALTHAND SAFETY
(1)
The Owner certifies that it is aware of its duties and obligations under the Occupational Health
and Safety Act, or any successor thereto, and all Regulations thereunder (in this section called the
"Act"), and shall ensure that its employees, contractors, subcontractors and their employees,
(a) are aware of their respective duties and obligations under the Act; and
(b) have sufficient knowledge and training to perform all works and services required
pursuant to this Agreement safely and in compliance with the Act.
(2)
In the performance of all works and services required pursuant to this Agreement, the Owner
shall,
(a) act safely and comply in all respects with the Act; and
(b)
ensure that its employees, contractors, subcontractors and their employees act safely and
comply in all respects with the Act.
(3)
The Owner shall rectify any unsafe act or practice and any non-compliance with the Act
immediately upon being notified by any person of the existence of such act, practice or non-
compliance.
(4)
The Owner shall permit representatives of the Town on the site where any works or services
required pursuant to this Agreement are being performed at any time or times for the purpose of
inspection to determine compliance with this section.
(5)
No act or omission by the Town or any representative of the Town (including the entering into of
this Agreement) shall be deemed to be an assumption of any of the duties or obligations of the
Owner, its employees, contractors, subcontractors and their employees under the Act.
(6)
In addition to the Owner's general indemnification of the Town pursuant to section 22, above, the
Owner shall indemnify and save harmless the Town,
(a)
from any loss, inconvenience, damage or cost to the Town which may result from the
Owner or any of its employees, contractors, subcontractors and their employees failing to
act safely or to comply in all respects with the Act in the performance of any work or
service required pursuant to this Agreement; and
11
(b)
against any action or claim, or costs related thereto, brought against the Town by any
person arising out of any unsafe act or practice or any non-compliance with the Act by
the Owner or any of its employees, contractors, subcontractors and their employees in the
performance of any work or service required pursuant to this Agreement.
24. LIABILITY INSURANCE POLICY / PROVISION FOR DEDUCTIBLE
(1)
Before this Agreement will be executed by the Town, the Owner shall file with the Town a
Certificate of Insurance verifying that a Liability Insurance Policy is in effect, setting out the
essential terms and conditions of the insurance, and naming the Town as additional named
insured, all of which shall be subject to the approval of the Town Solicitor.
(2) The policy shall comply with the following provisions:
(a)
the minimum limit per occurrence shall be $5,000,000 all inclusive for property damage
and personal liability;
(b) it shall not contain a clause for exclusion for blasting; and
(c)
it may not be cancelled unless prior notice by registered letter has been given to the Town
by the insurer thirty days in advance of the expiry date.
(3)
The policy premium must be paid initially for a period of one year and the policy shall be
renewed for further one year periods until the Final Acceptance Certificate has been issued by the
Town's Director of Public Works.
(4)
If the policy coverage is subject to a deductible amount, the Owner shall file with the Town,
when filing the Certificate of Insurance, a certified cheque or letter of credit with the Town in the
deductible amount, as a deposit, together with a letter from the Owner authorizing the Town to
appoint an independent adjuster and to investigate claims less than the deductible amount and
authorizing the Town to pay such claims deemed valid by the adjuster out of the deposit; the
Owner shall be responsible for all adjustment service costs and shall maintain the deposit
throughout the term of this agreement in the amount of the deductible.
(5)
The provision of the insurance policy required by this section shall not relieve the Owner from
liability for claims not covered by the policy or which exceed its limits, if any, for which the
Owner may be held responsible.
PART3-DEVELOPING THEPROJECT
25. CONSTRUCTION AND OCCUPANCY OF BUILDINGS
(1) No building permit shall be issued for any building or part of a building on the Lands until,
(a)
all buildings and structures on the Lands prior to draft plan approval have been
demolished by the Owner;
(b)
sewer and water facilities are available, and in the opinion of the Town's Director of
Public Works, capable of providing adequate service;
(c)
an asphalt base has been laid on the road immediately in front of the building or part
thereof and extended to an existing maintained road; and
(d)
the Owner has paid to the Town the applicable development charge for each dwelling in
that building or part thereof in accordance with By-law 3854/91, enacted pursuant to the
Development Charges Act.
12
(2)
No building or part of a building on the Lands shall be occupied except upon the issuance of a
municipal occupancy permit.
(3)
No application for a municipal occupancy permit for a building or part of a building shall be
made except upon the following conditions:
(a) storm sewer, sanitary sewer and water facilities are installed and in operation to
adequately serve such building or part thereof;
(b) electric service is completed and in operation; and
(c)
such curbs, as in the opinion of the Town's Director of Public Works, are required to be
completed prior to occupancy have been constructed on the road immediately in front of
the building or part thereof and extended to an existing maintained public road.
(4)
The Owner shall maintain vehicular access to all occupied buildings on the Lands until the roads
in the plan are formally assumed by the Town.
26. DESIGN PLANNING - RESIDENTIAL UNITS AND NOISE ATTENUATION STRUCTURES
(1)
Prior to the issuance of any building permit for the construction of any residential unit on the
Lands and the construction of any noise attenuation structure in or adjacent to the project, the
Owner shall submit to the Town's Director of Planning, for approval, a report outlining siting and
architectural design objectives for the project.
(2) That report may be required, at the Director's option, to provide the following information:
(a)
(b)
(c)
(d)
(e)
(f)
(g)
house massing;
streetscape;
exterior materials and colours;
architectural style;
visual variety;
energy conservation measures;
(h) building envelopes;
(i) house design and siting;
O) garage design; and
(k) projection from main building.
any other data or information reasonably required;
(3)
Prior to the issuance of each building permit for the construction of a residential unit on the
Lands, the Owner shall submit to the Town's Director of Planning, for approval, site plans and
architectural drawings for that unit.
(4)
Those plans and drawings may be required, at the Director's option, to provide the following
information:
(a)
(b)
(c)
(d)
(e)
(f)
the location of all buildings and structures to be erected and the location of all facilities
and works associated therewith;
the location of landscaping features, including trees to be preserved;
streetscape for front, rear and tankage elevations at a scale acceptable to the Director;
streetscape to show all street furniture and vegetation;
the relationship of buildings by blocks; and
any other data or information reasonably required.
27. SPECIFIC PROVISIONS RESPECTING DEVELOPMENT
The Owner shall comply with any specific provisions respecting the development of this project set out
in Schedule C.
13
PART 4 - FINANCIAL MATTERS
28.
EXPIRY OF SECURITIES
(1)
Should any letter of credit security required to be provided hereunder expire before the Town
releases the Owner from the terms and conditions hereof, the Owner shall provide to the Town at
least 30 days in advance of the expiry date of that security, a further security to take effect upon
the expiry.
(2) Such further security shall be in a form and amount satisfactory to the Town.
(3)
Should no such further security be provided as required, then the Town shall have the right to
convert the expiring security into cash and hold the cash in lieu of and for the same purposes as
the expiring security.
29.
PAYMENT OF LIENS AND OTHER CLAIMS
(1)
The Owner shall discharge or vacate any liens or claims filed with the Town or registered on title
to any Town-owned lands within thirty days of being requested to do so by the Town.
(2)
At the end of the maintenance period, as extended during any rectification period, the Owner
shall file with the Town a Statutory Declaration stating that,
(a)
all materials have been supplied and all services and works have been completed in the
project with respect to the construction and installation of Works and other services;
(b)
all accounts for work or service performed and materials placed or furnished upon or in
respect of the construction and installation of Works and other services in the project
have been fully paid and satisfied and no person is entitled to claim a lien under the
Construction Lien Act against the Town or any Town-owned land;
(c) there are no judgments or executions filed against the Owner;
(d)
nothing is owed by the Owner or claimed against it for unemployment insurance
deductions, income tax deductions, or by way of contribution or assessment under the
Workers' Compensation Act;
(e)
the Owner has not made any assignment for the benefit of creditors, nor has any receiving
order been made against it under the Bankruptcy Act, nor has any petition for such an
order been served upon the Owner; and
(f)
45 days have passed since the completion of the construction, installation, and last
rectification of the Works and services.
30.
PAYMENT OF INTEREST ON OVERDUE AMOUNTS PAYABLE
The Owner shall pay interest at the rate of 18 per cent per year to the Town on all sums of money
payable hereunder which are not paid on the due dates calculated from such due dates.
31. PAYMENT OF REALTY AND BUSINESS TAXES / LOCAL IMPROVEMENT CHARGES
(1)
The Owner shall pay in full as they come due all realty and business taxes assessed against the
Lands or the Owner as required by law from time to time.
14
(2)
Before this Agreement will be executed by the Town, the Owner shall commute and pay to the
Town or to the Regional Municipality of Durham all local improvement charges assessed against
the lands in the plan.
32.
PAYMENT OF DEVELOPMENT CHARGES
(1)
The Owner shall pay to the Town, in accordance with the Development Charges Act and the
Town's Development Charges By-law 3854/91, development charges for each dwelling unit
within the project.
(2)
The amount of the development charge for each dwelling to be erected in the plan shall be the
amount set out in Schedule B for that type of dwelling, as adjusted annually in accordance with
Schedule B.
(3)
Where a development charge is payable for a dwelling located on a parcel of land comprised of
land in this plan and land not in this plan, the amount of the development charge payable for that
dwelling shall be the amount calculated in accordance with the provisions of the subdivision
agreement for the most recently registered of the plan or plans within which the parcel is located.
33.
PAYMENT OF ENGINEERING, LEGAL AND REGISTRATION FEES
(1)
(2)
(3)
Prior to the release for registration of this plan, the Owner shall pay by certified cheque to the
Town an Engineering Drawing Inspection Fee in the amount set out in Schedule B for the
examination and inspection done by the Town's Public Works Department in the processing of
the engineering drawings for this project.
Prior to this Agreement being submitted to Town Council for consideration, the Owner shall pay
by certified cheque to the Town a Subdivision Agreement Processing Fee in the amount set out
in Schedule B for the preparation and processing of this Agreement by the Town's Legal Services
Department.
Prior to the release for registration of this plan, the Owner shall pay all registration costs incurred
by the Town relating in any way to the registration of the plan of subdivision, this Agreement, or
any other documentation, including transfers, in the Land Registry Office.
PART 5 - TRANSFERS AND REGISTRATIONS
34. TRANSFERS OF LANDS OR INTERESTS IN LANDS OR PAYMENTS IN LIEU THEREOF
(1)
(2)
(3)
(4)
Prior to the release for registration of this plan, the Owner shall convey or cause to be conveyed
to the Town, free and clear of all encumbrances and at no cost to the Town, all of the lands or
such interests in lands identified in Schedule A for the purposes set out therein.
The Owner hereby warrants that, upon such conveyance, neither the title to the lands conveyed
nor their physical state and condition shall prevent the Town from lawfully or physically using
the lands for the purposes for which they are being conveyed as set out in Schedule A.
Where none of the lands identified in Schedule A are to be conveyed for parkland purposes, the
Owner shall pay to the Town, before this Agreement will be executed by the Town, an amount
calculated in accordance with the provisions of Schedule A in lieu of a parkland conveyance.
Any Transfer/Deed given pursuant to this Agreement shall be in a form acceptable to the Town
Solicitor and any Transfer/Deed of a storm drainage works easement shall contain the Storm
Drainage Works Easement Schedule set out in Schedule A.
15
(5)
The Town may complete or alter any description of land in this Agreement or in any
Transfer/Deed given pursuant to this Agreement so as to make the description correspond with
the description of the land according to the plan which is to be registered pursuant to this
Agreement.
35. RELEASE OF THE PLAN FOR REGISTRATION
Before the Town will advise the Regional Municipality of Durham that the conditions of Draft Approval
affecting the Town have been satisfied, the Owner shall deliver to the Town the following:
(a) four red-lined copies of this Agreement executed by the Owner and all Encumbrancers;
(b) all monies, securities and insurance required by this Agreement;
(c)
three executed copies, in a form suitable for registration, of each Transfer/Deed required by
section 34 respecting the conveyances identified in Schedule A, and one draft copy of each
required reference plan; and
(d)
a certificate of clear title to the Lands being conveyed to the Town, from the Solicitor for the
Owner, in favour of the Town which certificate shall be prepared in a form acceptable to the
Town Solicitor at no cost to the Town.
36. REGISTRATION OF AGREEMENT
(1)
This Agreement shall be registered by the Town in the Land Registry Office in either the Land
Titles Division (No. 40) or the Land Registry Division of Durham, whichever is applicable to the
system in which the lands lie.
(2)
Prior to the registration of this Agreement, the Owner shall pay all registration costs relating in
any way to the registration of this Agreement, or any other documentation relating to this project.
(3)
Prior to the registration of this Agreement, the Owner's Solicitor will provide, at the Owner's
expense, a certificate of title, to the satisfaction of the Town Solicitor, of all the lands and
interests of lands conveyed to the Town as set out in Schedule A hereto.
(4)
The Owner shall indemnify and save harmless the Town from any loss, inconvenience or damage
which may result to the Town from the Owner's failure to comply with subsection (2) and against
any action or claim made against the Town by any person other than the Owner arising out of the
execution by the Town of this Agreement.
(5)
The Owner shall give to every purchaser of the Lands or any part of the Lands actual notice of
the existence and the terms of this Agreement and shall include an acknowledgment in any offer
to purchase or other similar document dealing with the Lands, or any part of them.
(6)
The Owner shall execute such further assurances of the rights hereby granted as may be deemed
necessary by the Town.
16
IN WITNESS WHEREOF the Parties hereto have hereunto affixed their respective Corporate Seals attested to
by the hands of their authorized officers.
SIGNED, SEALED AND DELIVERED
WOODSMERE PROPERTIES LIMITED
Gamet Watchom, President
I have the authority to bind the corporation.
THE CORPORATION OF THE TOWN OF PICKERING
Wayne Arthurs, Mayor
Bruce Taylor, Clerk
ENCUMBRANCER - THE BANK OF NOVA SCOTIA
The Encumbrancer hereby postpones any rights or interests which it has in the Lands with the intent that this
Agreement shall take effect as though executed and registered prior to the creation of any such right or interest
and prior to the execution and registration of any mortgage, agreement or other document creating or defining
any such right or interest;
And the Encumbrancer hereby covenants and agrees with the Town that this Agreement and any conveyance,
easement or other document given pursuant to this Agreement, shall have priority over the rights of the
Encumbrancer in the Lands with the intent that the Encumbrancer or anyone claiming under it shall at no time
exercise in relation to the Lands any right, title or claim which could not be exercised by the Owner by reason of
the terms of this Agreement.
Dated at , this day of ,1998.
SIGNED, SEALED AND DELIVERED
THE BANK OF NOVA SCOTIA
I/We have the authority to bind the corporation.
17
SCHEDULE A
TRANSFERS OF LANDS OR INTERESTS IN LANDS OR PAYMENTS IN LIEU THEREOF
(Section 34)
CONVEYANCES REQUIRED TO BE MADE TO THE TOWN
Land to be Conveyed
Purpose
Blocks 18 and 19
Reserves
Any portion of the lands
determined by the Town's
Director of Public Works
Storm drainage works
Any lands outside the Lands
determined by the Town's
Director of Public Works
Storm drainage works
Interest to be Conveyed
Fee Simple
Easement
Easement
2. CALCULATION OF AMOUNT PAYABLE IN LIEU OF PARKLAND CONVEYANCE
When Phase 4 of Draft Plan 18T-88074 was registered (now Plan 40M-1875), the Owner conveyed
Block 140 to the Town for parkland purposes. It was agreed betwee9 the parties that the conveyance of
Block 140 would satisfy the Town's requirement for parkland dedication for the Phase 4 development,
the Phase 5 development (now Plan 40M-1896) and also the Owner's requirement to provide parkland
for this development, which lands were originally designated as the Phase 6 development of Draft Plan
18T-88074.
Accordingly, the Town acknowledges that the Owner herein has satisfied its obligation to provide
parkland for this project.
o
STORM DRAINAGE WORKS EASEMENT REFERENCE PLANS
(1)
Before the Town will advise the Regional Municipality of Durham that the conditions of Draft
Approval affecting the Town have been satisfied, the Owner shall obtain and deliver to the Town
one draft copy of each proposed reference plan required to effect the conveyance of the specific
easements referred to in section 1 of this Schedule.
(2)
Upon the completion of the construction and installation of the storm drainage works within each
easement shown on any proposed reference plan, the Owner's Consulting Engineer shall advise
the Town's Director of Public Works of the actual location of the works in relation to the
proposed easement or easements, and if the Director is satisfied with the actual location of the
works, the Owner shall register that reference plan and provide four copies of the plan as
registered to the Town Solicitor.
(3)
If the Town's Director of Public Works is not satisfied with the actual location of the works in
relation to the proposed easement or easements, the Owner shall obtain and deliver to the Town
one draft copy of a revised proposed reference plan, and the provisions of subsection (2) and of
this subsection will continue to apply.
(4)
Where the Town's Director of Public Works determines that the Town requires easements not
specifically referred to in section 1 of this Schedule, the Owner shall obtain and deliver to the
Town one draft copy of each proposed reference plan required to effect the conveyance of the
such easements within 30 days of the Town's request to do so, and the provisions of subsections
(2) and (3) will apply.
18
4. STORM DRAINAGE WORKS EASEMENT SCHEDULE
Where a conveyance of an easement is for storm drainage works purposes, the following Schedule shall
be attached to the Transfer/Deed of Easement:
INTEREST/ESTATE TRANSFERRED
Subject to the following terms and conditions, the free, uninterrupted and unobstructed right and
easement to lay, construct, operate, maintain, inspect, alter, repair, replace, reconstruct and remove storm
drainage works together with appurtenances thereto (herein called the "works"), in, over, along, across,
upon and under the land described in Box 5 (herein called the "lands"), and to drain storm water in, over,
along, across, upon and under the lands, together with the fight to the Transferee, its servants, agents and
contractors with all necessary vehicles, supplies and equipment to enter onto the lands and pass and
repass over the lands for the purpose of exercising or enjoying any of the rights granted herein.
The terms and conditions which the parties hereto covenant and agree to observe and be bound by are as
follows:
The Transferee shall, except in case of emergency, before commencing any work authorized
hereby, give to the Transferor forty-eight hours previous written notice thereof, and in cases of
emergency such previous notice thereof as is reasonably possible.
Upon completion of any work, the Transferee shall fill in all excavations, restore fences, and
restore the surface of the ground by restoring all topsoil and grass cover disturbed thereby, and
do necessary grading to ensure soil and slope stability, and remove all equipment.
The Transferor shall not erect any building or structure (except a fence) on the lands, and shall
not place or remove any fill on or from any part of the lands without the previous written consent
of the Transferee.
The fight and easement granted herein shall be subject to all leases, licences, and any rights of
use or occupation existing at the date hereof, and the Transferor may from time to time renew or
extend these or make new ones, so long as they do not interfere unreasonably with the right and
easement herein granted.
o
The Transferor hereby releases the Transferee from any claim which may arise out of the
exercise by the Transferee of the right and easement granted hereby or which may arise out of the
existence of the storm water or the existence, operation or non-operation of the storm drainage
works provided the Transferee has complied with all of the terms and conditions herein.
The Transferor shall execute such further assurances of the right and easement granted hereby as
the Transferee may reasonably request in writing.
The burden of this Transfer and of all the terms and conditions contained herein shall mn with
the lands.
o
This Transfer and all of the terms and conditions contained herein shall enure to the benefit of
and be binding upon the Transferor and the Transferee and their respective heirs, executors,
administrators, successors and assigns.
LAND BENEFITTED (DOMINANT TENEMENT)
°
The benefit of this Transfer and all of the terms and conditions contained herein shall mn with all
other lands and interests in lands owned, occupied or used by the Transferee for the purpose of
operating and maintaining storm drainage works.
19
SCHEDULE B
DEVELOPMENT CItARGES, ENGINEERING/LEGAL FEES, OTItER RELATED
DEVELOPMENT COSTS
DEVELOPMENT CHARGES PAYABLE
(1)
Until and including October 7, 1998, the development charges payable under the Town's
Development Charges By-law 3854/91 for each semi-detached dwelling unit located on Lots 1
through 14 within this project are $5,530 and $5,111 for each townhouse unit located on Block
15.
(2)
From and after October 8, 1998, the development charges payable for dwelling units within this
project will be in accordance with the Town's Development Charges By-law in existence at the
date of such payment.
(3)
This draft plan of subdivision includes a block that is designated to be developed in conjunction
with abutting lands. Development Charge payments for the future development blocks in this
draft plan of subdivision will be collected at the time a building permit is issued for the
development of lands incorporating Block 16 of this draft plan and the abutting lands to the west
which fee will be payable by the registered owner of the developable lands at the time of
building permit issuance, in accordance with the Town's Development Charge By-Law in
existence at the date of such payment.
ENGINEERING DRAWING INSPECTION FEE PAYABLE
Prior to the release for registration of this plan, the Owner shall pay to the Town, the sum of $1,085.00,
which represents the mount of the Engineering Drawing Inspection Fee payable for this project.
o
SUBDIVISION AGREEMENT PROCESSING FEE PAYABLE
The Town acknowledges receipt, in full, of the amount of $3,210 [$3,000 plus $210 GST.] which
represents the Subdivision Agreement Processing Fee payable for this Agreement.
STROUD'S LANE CONSTRUCTION COST SHARING
(1)
Without limiting the generality of section 10 of this Agreement, the Owner shall include among
the works and services to be constructed and installed by it under this Agreement, the following:
(a)
a roadway (complete with all signs and other appurtenances) and having a total travelled
width of 13.5 metres; curbs and gutters; catch basins; a sidewalk (complete with
barricades); boulevard excavation, grading and sodding; driveway entrances; street
lighting; traffic calming measures; storm sewer connections; and concrete box culvert on
Stroud's Lane from the existing limit of Plan 40M-1810 to the west limit of Draft Plan
18T-96009.
(2)
Despite the provisions of section 8 of this Agreement the Town shall pay to the Owner all of the
Owner's reasonable costs,
(a)
up to a maximum of $175,000.00 of the design, construction and installation of the
roadway, sidewalk and boulevard excavation, box culvert installation, grading and
sodding, traffic calming measures and street lighting referred to in paragraph (1)(a) of this
section, within thirty days of receiving the Owner's invoices therefore supported by
appropriate progress certificates, certifications and declarations.
20
SCHEDULE C
SPECIFIC PROVISIONS RESPECTING DEVELOPMENT
1. EXPECTED NUMBER OF DWELLINGS
(1) This Agreement has been entered into with the expectation that 31 dwellings are to be
constructed on the Lands, two each on Lots 1-14 and three on Block 15.
(2)
If more or less than 31 dwellings are to be constructed in this project, the Town at its sole
discretion may require the Owner to obtain new approvals and authorizations under this
Agreement and may prohibit any development until the new approvals and authorizations are
obtained.
2. SPECIAL PROVISION RESPECTING CONSTRUCTION OF ROADS
The Owner herein agrees to the construction of internal roads with curb, storm sewer or sidewalk and
boulevard designs to maximize front yard space without impeding services or the safe operation of the
streets to the satisfaction of the Town's Director of Public Works.
3. CONSTRUCTION MANAGEMENT REPORT
Prior to the initiation of construction on the site, the Owner shall submit to the Town's Director of
Public Works for approval, a Construction Management Report outlining the site management measures
to be undertaken during construction.
4. STORMWATER DRAINAGE AND MANAGEMENT SYSTEM
The Owner herein shall satisfy the Town's Director of Public Works respecting a stormwater drainage
and management system to service all the lands in the subdivision and any provisions regarding related
required easements. Stormwater management techniques for this plan of subdivision shall be consistent
with those approved for the Altona Forest Environmental Policy Area, including compliance with all
erosion and sediment control strategies to the satisfaction of the Town's Director of Public Works.
5. SPECIAL PROVISION RESPECTING DESIGN PLANNING
In addition to section 26 herein, the Owner agrees that the required report shall place special emphasis
on massing, method of attachment and garage siting, the provision of adequate on and off-street parking
and the design of high visibility building elevations adjacent to public areas, including the rear
elevations of dwelling units on Lots 10-14 as shown on draft plan of subdivision 18T-96009.
6. FUTURE DEVELOPMENT - BLOCK 16
(1)
Block 16 shall be reserved for future residential development; such development shall not
commence without servicing availability from the adjacent lands to the west and the prior written
approval of the Town, which may be subject to conditions.
(2)
Until such time as Block 16 is developed in accordance herewith, the Owner shall maintain it in a
clean and orderly condition to the satisfaction of the Town's Director of Public Works.
(3)
In the event that Block 16 is not developed in accordance herewith prior to the request for the
issuance by the Town of the Final Acceptance Certificate, the Owner agrees to sod and grade
Block 16 to the satisfaction of the Town's Director of Public Works, prior to the issuance of the
Final Acceptance Certificate being issued.
21
SCHEDULE D
SPECIAL PROVISIONS REQUIRED BY THE REGIONAL MUNICIPALITY OF DURHAM
The sections set out in this Schedule represent provisions not affecting the Town, but required to be inserted in
this Agreement by the conditions of the Ontario Municipal Board dated May 7, 1997, of Draft Plan 18T-96009
(the "Approval").
TORONTO AND REGION CONSERVATION AUTHORITY
The Owner herein acknowledges that prior to final registration of the plan of subdivision, or any on-site
grading, the Toronto and Region Conservation Authority and the Town must have reviewed and
approved the following reports and/or plans describing:
(a) the storm drainage system for the proposed development, which report must include:
(i)
details of compliance with the reports entitled "Hydrology and Hydraulics Update for
Main Petticoat Creek - Stage 1 Study of Comprehensive Stormwater Management for
Altona Forest Area, 194" and "Stormwater Management Strategy for the Altona Forest
Area, February 1994", prepared by Cosbum Patterson Wardman Limited;
(ii)
the manner in which stormwater will be conveyed from the site, including how the
subdivision ties into existing development;
(iii)
appropriate Stormwater Management Practices (SWAPs) to be used to treat stormwater,
to ensure no negative impact on the quality and quantity of ground and surface water
resources;
(iv)
the location and description of all outlets and other facilities which may require permits
under provincial regulations; and
(v)
proposed methods of controlling or minimizing erosion and siltation on-site and in
downstream areas during and after construction; an erosion sediment control strategy
which includes a description and plan be prepared.
(b) Overall grading plans for the lands within this plan.
(c)
A landscape plan showing the location of tree planting between Tree Top Crescent and the
abutting valleylands as shown on Draft Plan 18T-96009.
The Owner agrees to submit to the Town and the Toronto and Region Conservation Authority for
approval, the final engineering and construction drawings for the Stroud's Lane crossing of the
Rosebank tributary, such drawings to be substantially in accordance with the drawings contained in the
witness statement of Robert Webb, Marshall, Macklin, Monaghan, dated February, 1994.
The Owner agrees to prepare and submit a Grading Control Plan and any other drainage information
required to the satisfaction of the Town and the Toronto and Region Conservation Authority with special
emphasis on coordinating grades with adjacent plans of subdivision and minimizing lot grading adjacent
to the valley lands and the Altona Forest.
The Owner agrees to prepare an Edge Management Report in accordance with the Altona Forest
Management Plan for the review and approval of the Toronto and Region Conservation Authority and to
the satisfaction of the Town.
The Owner agrees to demonstrate compliance with the recommendations of the "Slope Stability
Investigation at the Highbush Subdivision, Town of Picketing" prepared by Marshall, Macklin,
Monaghan Limited, dated January 1994.
22
o
(a)
The Owner agrees to construct permanent fencing in accordance with Toronto and Region
Conservation Authority specifications along the length of development adjacent to the valley and
forest preserve blocks.
(b)
The Owner agrees to construct the permanent fencing referred to in Condition 6(a) prior to
occupancy or within 6 months of date of occupancy if occupancy occurs within the winter
months.
The Owner agrees to obtain all necessary permits required under Provincial Regulation, prior to the
registration of the plan.
8. The Owner agrees to:
(a) cause to carry out the works referred to in conditions 1, 2, 3 and 5 above;
(b)
design and implement on-site erosion and sediment control, in order to meet the
requirements of the Federal Fisheries Act. The Ministry of Natural Resources will
monitor effectiveness and take appropriate action as required; and
(c)
maintain all stormwater management and erosion and sedimentation control structures
operating and in good repair during the construction period, in a manner satisfactory to
the Toronto and Region Conservation Authority and the Town.
Once the Subdivision Agreement between the Town of Picketing and the Owner herein is fully-
executed, the Owner agrees to forward a copy to the Toronto and Region Conservation Authority.
CANADA POST CORPORATION
Prior to final registration of this plan, the Owner herein agrees to provide a central mail facility at their expense
and have the location reviewed by the Town and approved by Canada Post Corporation.
18T-96009
23
Province
of
Ontario
New Propen'y Identifiers
Additional:
Schedule
Executions
Transfer/Deed of Land
Form 1 -- Land Registration Reform ~ ~-~ TO REPORT
T
Land Tltte~ [] (2) Page 1 of
(1) negmry []
(3) Propady Block Property
Idemlltar(s)
(4) Consideration
Dollars $
(5) Description This is a: Property Property
Division [] Consolidation []
Additional:
See
Schedule []
(6) This (a) Redescription i(b) Schedule for'
Do. merit New Easement Additional
Contains Plan/Sketch [] ; Description [] Parties [] Other []
(7) Intere~VEstate Transferred
Fee Simple
Amended NOV. 1992
pages
(8) Transferors) The transferor hereby transfers the land to the transferee and certifies that the transferor is at least eighteen years old and that
Additional:
see I---
Schedule
Date of Signature
............................................................................... Y M D
Name(s) Signature(s)
(9) Spouse(s) of Transferor(s) I hereby consent to this transachon Date of Signature
Name(s) Signature(s) Y M D
(10) Transferor(s) Address
for Se~..e
>(11 ) Transferee(s)
Date of Birth
Y M D
...... ........................................................... : .......
Wayne Arthurs, ~yor
~ OF PICKER.ING :
Bruce Taylor, Clerk ;
,
(12) Transferee(s) Address
for Service Pi ..... i
> ckerLn9 Civic Centrer One The Esplanader Plcker~ngr Ontar o L1V 6K7
(13) Transferor(e) The transferor verifies that to the best of the transferor's knowledge and belief, this transfer does not contravene section 50 of the Planning Act.
I Date of Signature Date of Signature
I , Y , M OI , Y , M ~ D
Si nature I : Sgnature :
I Solicitor for Transferor(s) I have explained the effect of section 50 of the Planning Act to the transferor and I have made ~nquines of the transferor to,
~ determine that this transfer does not contravene that section and based on the information supplied by the transferor, to the best of my knowledge eno
z ~ belief, this transfer does not contravene that section. I am an Ontario solicitor in good standing. Date of Signature
~l Name and ; Y I Mi D
n ! Address of '
O ~ Solicitor Signature ................................. * ........
I
~ ! ~' I (14) Solicitor for Transferee(s) I have investigated the title to this land and to abutting land where relevant and I am satisfied that the title records
'~ I~ ~-I reveal no contravention as set out in subclause 50 (22) (c) (ii) of the Planning Act and that to the best of my knowledge and belief this transfei
~IE'~ ,~J does not contravene section 50 of the Planning Act. I act independently of the solicitor for the transferor(s) and I am an Ontario solicitor in good standing.
~I~1 '
3. J~= Name and Date of S,gnature
I.; ~1 Address of Y M , D
Solicitor :
I I
(15) Assessment Roll Number
of Property
7(16) Municipal Address of Property
· Cb/. iMun. i Map
Sub.
Par.
(17)' Oocum;n, Prepare~l by:.
Tc~n of Pickering
One The Esplanade
Pickering, Ontario
L1V 6K7
Total